PART 852 - SOLICITATION PROVISIONS AND CONTRACT CLAUSES

852.201-70 Contracting Officer's Representative.

As prescribed in 801.604, insert the following provision:

Contracting Officer's Representative (DEC 2022)

The Contracting Officer reserves the right to designate representatives to act for him/her in furnishing technical guidance and advice or generally monitor the work to be performed under this contract. Such designation will be in writing and will define the scope and limitation of the designee's authority. A copy of the designation letter shall be furnished to the Contractor.

(End of provision)

852.203-70 Commercial Advertising.

As prescribed in 803.570-2, insert the following clause:

Commercial Advertising (MAY 2018)

The Contractor shall not make reference in its commercial advertising to Department of Veterans Affairs contracts in a manner that states or implies the Department of Veterans Affairs approves or endorses the Contractor's products or services or considers the Contractor's products or services superior to other products or services.

(End of clause)

852.203-71 [Reserved]

852.204-70 Personal Identity Verification of Contractor personnel.

As prescribed in 804.1303, insert the following clause:

Personal Identity Verification of Contractor Personnel (MAY 2020)

(a) The Contractor shall comply with current Department of Veterans Affairs policy for personal identity verification of all employees performing under this contract when frequent and continuing access to VA facilities or information systems is required.

(b) The Contractor shall insert this clause in all subcontracts when the subcontractor's employees will require frequent and continuing access to VA facilities or information systems.

(End of clause)

852.204-71 Information and Information Systems Security.

As prescribed in 804.1903, insert the following clause:

Information and Information Systems Security (FEB 2023)

(a) Definitions. As used in this clause -

Business Associate means an entity, including an individual (other than a member of the workforce of a covered entity), company, organization or another covered entity, as defined by the Health Insurance Portability and Accountability Act of 1996 (HIPAA) Privacy Rule, that performs or assists in the performance of a function or activity on behalf of the Veterans Health Administration (VHA) that involves the creating, receiving, maintaining, transmitting of, or having access to, protected health information (PHI). The term also includes a subcontractor of a business associate that creates, receives, maintains, or transmits PHI on behalf of the business associate.

Business Associate Agreement (BAA) means the agreement, as dictated by the Privacy Rule, between VHA and a business associate, which must be entered into in addition to the underlying contract for services and before any release of PHI can be made to the business associate, in order for the business associate to perform certain functions or activities on behalf of VHA.

Information system means a discrete set of information resources organized for the collection, processing, maintenance, use, sharing, dissemination, or disposition of information whether automated or manual.

Information technology (see FAR 2.101) also means Information and Communication Technology (ICT).

Information technology-related contracts means those contracts which include services (including support services), and related resources for information technology as defined in 802.101.

Privacy officer means the VA official with responsibility for implementing and oversight of privacy related policies and practices that impact a given VA acquisition.

Sensitive personal information means, with respect to an individual, any information about the individual maintained by VA, including but not limited to the following:

(1) Education, financial transactions, medical history, and criminal or employment history.

(2) Information that can be used to distinguish or trace the individual's identity, including but not limited to name, social security number, date and place of birth, mother's maiden name, or biometric records.

Security plan means a formal document that provides an overview of the security requirements for an information system or an information security program and describes the security controls in place or planned for meeting those requirements.

VA Information Security Rules of Behavior for Organizational Users (VA National Rules of Behavior) means a set of VA rules that describes the responsibilities and expected behavior of users of VA information or information systems.

VA sensitive information means all VA data, on any storage media or in any form or format, which requires protection due to the risk of harm that could result from inadvertent or deliberate disclosure, alteration, or destruction of the information and includes sensitive personal information. The term includes information where improper use or disclosure could adversely affect the ability of VA to accomplish its mission, proprietary information, records about individuals requiring protection under various confidentiality provisions such as the Privacy Act and the HIPAA Privacy Rule, and information that can be withheld under the Freedom of Information Act. Examples of VA sensitive information include the following: individually-identifiable medical, benefits, and personnel information; financial, budgetary, research, quality assurance, confidential commercial, critical infrastructure, investigatory, and law enforcement information; information that is confidential and privileged in litigation such as information protected by the deliberative process privilege, attorney work-product privilege, and the attorney-client privilege; and other information which, if released, could result in violation of law or harm or unfairness to any individual or group, or could adversely affect the national interest or the conduct of Federal programs.

(b) General. Contractors, subcontractors, their employees, third-parties, and business associates with access to VA information, information systems, or information technology (IT) or providing and accessing IT-related goods and services, shall adhere to VA Directive 6500, VA Cybersecurity Program, and the directives and handbooks in the VA 6500 series related to VA information (including VA sensitive information and sensitive personal information and information systems security and privacy), as well as those set forth in the contract specifications, statement of work, or performance work statement. These include, but are not limited to, VA Handbook 6500.6, Contract Security; and VA Directive and Handbook 0710, Personnel Security and Suitability Program, which establishes VA's procedures, responsibilities, and processes for complying with current Federal law, Executive Orders, policies, regulations, standards and guidance for protecting VA information, information systems (see 802.101, Definitions) security and privacy, and adhering to personnel security requirements when accessing VA information or information systems.

(c) Access to VA information and VA information systems.

(1) Contractors are limited in their request for logical or physical access to VA information or VA information systems for their employees, subcontractors, third parties and business associates to the extent necessary to perform the services or provide the goods as specified in the contracts, agreements, task, delivery or purchase orders.

(2) All Contractors, subcontractors, third parties, and business associates working with VA information are subject to the same investigative requirements as those of VA appointees or employees who have access to the same types of information. The level and process of background security investigations for contractors to access VA information and VA information systems shall be in accordance with VA Directive and Handbook 0710, Personnel Security and Suitability Program.

(3) Contractors, subcontractors, third parties, and business associates who require access to national security programs must have a valid security clearance.

(4) HIPAA Business Associate Agreement requirement. Contractors shall enter into a Business Associate Agreement (BAA) with VHA, VA's Covered Entity, when contract requirements and access to protected health information is required and when requested by the Contracting Officer, or the Contracting Officer's Representative (COR) (see VAAR 824.103-70). Under the HIPAA Privacy and Security Rules, a Covered Entity (VHA) must have a satisfactory assurance that its PHI will be safeguarded from misuse. To do so, a Covered Entity enters into a BAA with a contractor (now the business associate), which obligates the business associate to only use the Covered Entity's PHI for the purposes for which it was engaged, provide the same protections and safeguards as is required from the Covered Entity, and agree to the same disclosure restrictions to PHI that is required of the Covered Entity in situations where a contractor -

(i) Creates, receives, maintains, or transmits VHA PHI or that will store, generate, access, exchange, process, or utilize such PHI in order to perform certain health care operations activities or functions on behalf of the Covered Entity; or

(ii) Provides one or more of the services specified in the Privacy Rule to or for the Covered Entity.

(A) Contractors or entities required to execute BAAs for contracts and other agreements become VHA business associates. BAAs are issued by VHA or may be issued by other VA programs in support of VHA. The HIPAA Privacy Rule requires VHA to execute compliant BAAs with persons or entities that create, receive, maintain, or transmit VHA PHI or that will store, generate, access, exchange, process, or utilize such PHI in order to perform certain activities, functions or services to, for, or on behalf of VHA. There may be other VA components or staff offices which also provide certain services and support to VHA and must receive PHI in order to do so. If these components award contracts or enter into other agreements, purchase/delivery orders, modifications and issue governmentwide purchase card transactions to help in the delivery of these services to VHA, they will also fall within the requirement to obtain a satisfactory assurance from these contractors by executing a BAA.

(B) BAA requirement flow down to subcontractors. A prime Contractor required to execute a BAA shall also obtain a satisfactory assurance, in the form of a BAA, that any of its subcontractors who will also create, receive, maintain, or transmit VHA PHI or that will store, generate, access, exchange, process, or utilize such PHI will comply with HIPAA requirements to the same degree as the Contractor. Contractors employing a subcontractor who creates, receives, maintains, or transmits VHA PHI or that will store, generate, access, exchange, process, or utilize such VHA PHI under a contract or agreement is required to execute a BAA with each of its subcontractors which also obligates the subcontractor (i.e., also a business associate) to provide the same protections and safeguards and agree to the same disclosure restrictions to VHA's PHI that is required of the Covered Entity and the prime Contractor.

(d) Contractor operations required to be in United States. Custom software development and outsourced operations must be located in the U.S. to the maximum extent practicable. If such services are proposed to be performed outside the continental United States, and are not otherwise disallowed by other Federal law, regulations or policy, or other VA policy or other mandates as stated in the contract, specifications, statement of work or performance work statement (including applicable Business Associate Agreements), the Contractor/subcontractor must state in its proposal where all non-U.S. services are provided. At a minimum, the Contractor/subcontractor must include a detailed Information Technology Security Plan, for review and approval by the Contracting Officer, specifically to address mitigation of the resulting problems of communication, control, and data protection.

(e) Contractor/subcontractor employee reassignment and termination notification. Contractors and subcontractors shall provide written notification to the Contracting Officer and Contracting Officer's Representative (COR) immediately, and not later than four (4) hours, when an employee working on a VA information system or with access to VA information is reassigned or leaves the Contractor or subcontractor's employment on the cognizant VA contract. The Contracting Officer and COR must also be notified immediately by the Contractor or subcontractor prior to an unfriendly termination.

(f) VA information custodial requirements.

(1) Release, publication, and use of data. Information made available to a Contractor or subcontractor by VA for the performance or administration of a contract or information developed by the Contractor/subcontractor in performance or administration of a contract shall be used only for the stated contract purpose and shall not be used in any other way without VA's prior written approval. This clause expressly limits the Contractor's/subcontractor's rights to use data as described in Rights in Data - General, FAR 52.227-14(d).

(2) Media sanitization. VA information shall not be co-mingled with any other data on the Contractors/subcontractor's information systems or media storage systems in order to ensure federal and VA requirements related to data protection, information segregation, classification requirements, and media sanitization can be met (see VA Directive 6500, VA Cybersecurity Program). VA reserves the right to conduct scheduled or unscheduled on-site inspections, assessments, or audits of Contractor and subcontractor IT resources, information systems and assets to ensure data security and privacy controls, separation of data and job duties, and destruction/media sanitization procedures are in compliance with Federal and VA requirements. The Contractor and subcontractor will provide all necessary access and support to VA and/or GAO staff during periodic control assessments or audits.

(3) Data retention, destruction, and contractor self-certification. The Contactor and its subcontractors are responsible for collecting and destroying any VA data provided, created, or stored under the terms of this contract, to a point where VA data or materials are no longer readable or reconstructable to any degree, in accordance with VA Directive 6371, Destruction of Temporary Paper Records, or subsequent issue. Prior to termination or completion of this contract, the Contractor/subcontractor must provide its plan for destruction of all VA data in its possession according to VA Handbook 6500, and VA Cybersecurity Program, including compliance with National Institute of Standards and Technology (NIST) 800-88, Guidelines for Media Sanitization, for the purposes of media sanitization on all IT equipment. The Contractor must certify in writing to the Contracting Officer within 30 days of termination of the contract that the data destruction requirements in this paragraph have been met.

(4) Return of VA data and information. When information, data, documentary material, records and/or equipment is no longer required, it shall be returned to the VA (as stipulated by the Contracting Officer or the COR) or the Contractor/subcontractor must hold it until otherwise directed. Items returned will be hand carried, securely mailed, emailed, or securely electronically transmitted to the Contracting Officer or to the address as provided in the contract or by the assigned COR, and/or accompanying BAA. Depending on the method of return, Contractor/subcontractor must store, transport, or transmit VA sensitive information, when permitted by the contract using VA-approved encryption tools that are, at a minimum, validated under Federal Information Processing Standards (FIPS) 140-3 (or its successor). If mailed, Contractor/subcontractor must send via a trackable method (USPS, UPS, Federal Express, etc.) and immediately provide the Contracting Officer with the tracking information. No information, data, documentary material, records or equipment will be destroyed unless done in accordance with the terms of this contract and the VHA Records Control Schedule 10-1.

(5) Use of VA data and information. The Contractor/subcontractor must receive, gather, store, back up, maintain, use, disclose and dispose of VA information only in compliance with the terms of the contract and applicable Federal and VA information confidentiality and security laws, regulations and policies. If Federal or VA information confidentiality and security laws, regulations and policies become applicable to the VA information or information systems after execution of the contract, or if the National NIST issues or updates applicable FIPS or Special Publications (SP) after execution of this contract, the parties agree to negotiate in good faith to implement the information confidentiality and security laws, regulations and policies for this contract as a result of any updates, if required.

(6) Copying VA data or information. The Contractor/subcontractor shall not make copies of VA information except as authorized and necessary to perform the terms of the contract or to preserve electronic information stored on Contractor/subcontractor electronic storage media for restoration in case any electronic equipment or data used by the Contractor/subcontractor needs to be restored to an operating state. If copies are made for restoration purposes, after the restoration is complete, the copies must be appropriately destroyed.

(7) Violation of information custodial requirements. If VA determines that the Contractor has violated any of VA's information confidentiality, privacy, or security provisions, it shall be sufficient grounds for VA to withhold payment to the Contractor or third-party or terminate the contract for default in accordance with FAR part 49 or terminate for cause in accordance with FAR 12.403.

(8) Encryption. The Contractor/subcontractor must store, transport, or transmit VA sensitive information, when permitted by the contract, using cryptography, and VA-approved encryption tools that are, at a minimum, validated under FIPS 140-3 (or its successor).

(9) Firewall and web services security controls. The Contractor/subcontractor's firewall and web services security controls, if applicable, shall meet or exceed VA's minimum requirements. VA Configuration Guidelines are available upon request.

(10) Disclosure of VA data and information. Except for uses and disclosures of VA information authorized in a cognizant contract for performance of the contract, the Contractor/subcontractor may use and disclose VA information only in two other situations:

(i) subject to paragraph (f)(10) of this section, in response to a court order from a court of competent jurisdiction, or (ii) with VA's prior written approval. The Contractor/subcontractor must refer all requests for, demands for production of, or inquiries about, VA information and information systems to the Contracting Officer for response. If the Contractor/subcontractor is in receipt of a court order or other request or believes it has a legal requirement to disclose VA information, that Contractor/subcontractor shall immediately refer such court order or other request to the Contracting Officer for response. If the Contractor or subcontractor discloses information on behalf of VHA, the Contractor and/or subcontractor must maintain an accounting of disclosures. Accounting of Disclosures documentation maintained by the Contractor/subcontractor will include the name of the individual to whom the information pertains, the date of each disclosure, the nature or description of the information disclosed, a brief statement of the purpose of each disclosure or, in lieu of such statement, a copy of a written request for a disclosure, and the name and address of the person or agency to whom the disclosure was made. The Contractor/subcontractor will provide its Accounting of Disclosures upon request and within 15 calendar days to the assigned COR and Privacy Officer. Accounting of disclosures should be provided electronically via encrypted email to the COR and designated VA facility Privacy Officer as provided in the contract, BAA, or by the Contracting Officer. If providing the Accounting of Disclosures electronically cannot be done securely, the Contractor/subcontractor will provide copies via trackable methods (UPS, USPS, Federal Express, etc.) immediately, providing the designated COR and Privacy Officer with the tracking information.

(11) Compliance with privacy statutes and applicable regulations. The Contractor/subcontractor shall not disclose VA information protected by any of VA's privacy statutes or applicable regulations including but not limited to: the Privacy Act of 1974, 38 U.S.C. 5701, confidential nature of claims, 38 U.S.C. 5705, confidentiality of medical quality assurance records and/or 38 U.S.C. 7332, confidentiality of certain health records pertaining to drug addiction, sickle cell anemia, alcoholism or alcohol abuse, or infection with human immunodeficiency virus or the HIPAA Privacy Rule. If the Contractor/subcontractor is in receipt of a court order or other requests for VA information or has questions if it can disclose information protected under the above-mentioned confidentiality statutes because it is required by law, that Contractor/subcontractor shall immediately refer such court order or other request to the Contracting Officer for response.

(g) Report of known or suspected security/privacy incident. The Contractor, subcontractor, third-party affiliate or business associate, and its employees shall notify VA immediately via the Contracting Officer and the COR or within one

(1) hour of an incident which is an occurrence (including the discovery or disclosure of successful exploits of system vulnerability) that (A) actually or imminently jeopardizes, without lawful authority, the integrity, confidentiality, or the availability of its data and operations, or of its information or information system(s); or (B) constitutes a violation or imminent threat of violation of law, security policies, security procedures, or acceptable use policies. The initial notification may first be made verbally but must be followed up in writing within one

(1) hour. See VA Data Breach Response Service at https://www.oprm.va.gov/dbrs/about_dbrs.aspx. Report all actual or suspected security/privacy incidents and report the information to the Contracting Officer and the COR as identified in the contract or as directed in the contract, within one hour of discovery or suspicion.

(1) Such issues shall be remediated as quickly as is practical, but in no event longer than __ days [Fill in: Contracting Officer fills in the number of days]. The Contractor shall notify the Contracting Officer in writing.

(2) When the security fixes involve installing third party patched (e.g., Microsoft OS patches or Adobe Acrobat), the Contractor will provide written notice to VA that the patch has been validated as not affecting the systems within 10 working days. When the Contractor is responsible for operations or maintenance of the systems, they shall apply the security fixes within __ [Fill in: Contracting Officer fills in the number of days in consultation with requiring activity].

(3) All other vulnerabilities shall be remediated in a timely manner based on risk, but within 60 days of discovery or disclosure. Contractors shall notify the Contracting Officer, and COR within 2 business days after remediation of the identified vulnerability. Exceptions to this paragraph (e.g., for the convenience of VA) must be requested by the Contractor through the COR and shall only be granted with approval of the Contracting Officer and the VA Assistant Secretary for Office of Information and Technology. These exceptions will be tracked by the Contractor in concert with the Government in accordance with VA Directive 6500.6 and related VA Handbooks.

(h) Security and privacy incident investigation.

(1) The term “privacy incident” means the unauthorized disclosure or use of VA information protected under a confidentiality statute or regulation.

(2) The term “security incident” means an occurrence that (A) actually or imminently jeopardizes, without lawful authority, the integrity, confidentiality, or availability of information systems; or (B) constitutes a violation or imminent threat of violation of law, security policies, security procedures, or acceptable policies. The Contractor/subcontractor shall immediately notify the Contracting Officer and COR for the contract of any known or suspected security or privacy incident, or any other unauthorized disclosure of sensitive information, including that contained in system(s) to which the Contractor/subcontractor has access.

(3) To the extent known by the Contractor/subcontractor, the Contractor/subcontractor's notice to VA shall identify the information involved, the circumstances surrounding the incident (including to whom, how, when, and where the VA information or assets were placed at risk or compromised), and any other information that the Contractor/subcontractor considers relevant.

(4) With respect to unsecured PHI, the Business Associate is deemed to have discovered a security incident as defined above when the Business Associate either knew, or by exercising reasonable diligence should have been known to an employee of the Business Associate. Upon discovery, the Business Associate must notify VHA of the security incident immediately within one hour of discovery or suspicion as agreed to in the BAA.

(5) In instances of theft or break-in or other criminal activity, the Contractor/subcontractor must concurrently report the incident to the appropriate law enforcement entity (or entities) of jurisdiction, including the VA OIG and the VA Office of Security and Law Enforcement. The Contractor, its employees, and its subcontractors and their employees shall cooperate with VA and any law enforcement authority responsible for the investigation and prosecution of any possible criminal law violation(s) associated with any incident. The Contractor/subcontractor shall cooperate with VA in any civil litigation to recover VA information, obtain monetary or other compensation from a third party for damages arising from any incident, or obtain injunctive relief against any third party arising from, or related to, the incident.

(i) Data breach notification requirements. (1) This contract may require access to sensitive personal information. If so, the Contractor is liable to VA for liquidated damages in the event of a data breach involving any VA sensitive personal information the Contractor/Subcontractor processes or maintains under the contract as set forth in clause 852.211-76, Liquidated Damages - Reimbursement for Data Breach Costs.

(2) The Contractor/subcontractor shall provide notice to VA of a privacy or security incident as set forth in the Security and Privacy Incident Investigation section of this clause. The term 'data breach' means the loss, theft, or other unauthorized access, or any access other than that incidental to the scope of employment, to data containing sensitive personal information, in electronic or printed form, that results in the potential compromise of the confidentiality or integrity of the data. The Contractor shall fully cooperate with VA or third-party entity performing an independent risk analysis on behalf of VA. Failure to cooperate may be deemed a material breach and grounds for contract termination.

(3) The Contractor/subcontractor shall fully cooperate with VA or any Government agency conducting an analysis regarding any notice of a data breach or potential data breach or security incident which may require the Contractor to provide information to the Government or third-party performing a risk analysis for VA, and shall address all relevant information concerning the data breach, including the following:

(i) Nature of the event (loss, theft, unauthorized access).

(ii) Description of the event, including -

(A) Date of occurrence;

(B) Date of incident detection;

(C) Data elements involved, including any PII, such as full name, social security number, date of birth, home address, account number, disability code.

(D) Number of individuals affected or potentially affected.

(E) Names of individuals or groups affected or potentially affected.

(F) Ease of logical data access to the lost, stolen or improperly accessed data in light of the degree of protection for the data, e.g., unencrypted, plain text.

(G) Amount of time the data has been out of VA control.

(H) The likelihood that the sensitive personal information will or has been compromised (made accessible to and usable by unauthorized persons).

(I) Known misuses of data containing sensitive personal information, if any.

(J) Assessment of the potential harm to the affected individuals.

(K) Data breach analysis as outlined in 6500.2 Handbook, Management of Breaches Involving Sensitive Personal Information, as appropriate.

(L) Whether credit protection services may assist record subjects in avoiding or mitigating the results of identity theft based on the sensitive personal information that may have been compromised.

(M) Steps taken in response to mitigate or prevent a repetition of the incident.

(j) Training.

(1) All Contractor employees and subcontractor employees requiring access to VA information or VA information systems shall complete the following before being granted access to VA information and its systems:

(i) On an annual basis, successfully complete the VA Privacy and Information Security Awareness and VA Information Security Rules of Behavior training.

(ii) On an annual basis, sign and acknowledge (either manually or electronically) understanding of and responsibilities for compliance with the VA Information Security Rules of Behavior for Organizational Users, relating to access to VA information and information systems.

(iii) Successfully complete any additional cyber security or privacy training, as required for VA personnel with equivalent information system access.

(2) The Contractor shall provide to the Contracting Officer and/or the COR a copy of the training certificates and affirmation that VA Information Security Rules of Behavior for Organizational Users signed by each applicable employee have been completed and submitted within five (5) days of the initiation of the contract and annually thereafter, as required.

(3) Failure to complete the mandatory annual training and acknowledgement of the VA Information Security Rules of Behavior, within the timeframe required, is grounds for suspension or termination of all physical or electronic access privileges and removal from work on the contract until such time as the training and documents are complete.

(k) Subcontract flow down. The Contractor shall include the substance of this clause, including this paragraph (k), in subcontracts, third-party agreements, and BAAs, of any amount and in which subcontractor employees, third-party servicers/employees, and business associates will perform functions where they will have access to VA information (including VA sensitive information, i.e., sensitive personal information and protected health information), information systems, information technology (IT) or providing and accessing information technology-related contract services, support services, and related resources (see VAAR 802.101 definition of information technology-related contracts).

(End of clause)

852.207-70 [Reserved]

852.208-70 Service-Disabled Veteran-Owned and Veteran-Owned Small Business Evaluation Factors - Orders or BPAs.

As prescribed in 808.405-570, insert the following clause:

Service-Disabled Veteran-Owned and Veteran-Owned Small Business Evaluation Factors - Orders or BPAs (Nov 2022)

(a) In an effort to increase contracting opportunities for Veterans, depending on the evaluation factors included in the solicitation, VA will evaluate responses received based on the schedule Contractor's VIP-verified service-disabled veteran-owned small business/veteran-owned small business (SDVOSB/VOSB) status; and/or their proposed use of VIP-listed SDVOSB/VOSB as subcontractors or teaming partners.

(b) To receive credit under this clause a contractor or subcontractor must be listed, at time of submission of offer/quotes and at time of award, as an eligible SDVOSB/VOSB in the Vendor Information Pages (VIP) database at https://www.vetbiz.va.gov/vip/.

(c) A VIP-listed SDVOSB schedule holder will receive full credit, and a VIP-listed VOSB schedule holder will receive partial credit for the SDVOSB/VOSB status evaluation factor.

(d) Offerors other than SDVOSBs or VOSBs proposing to use VIP-listed SDVOSBs/VOSBs as subcontractors/teaming partners, will receive some consideration under this evaluation factor. To receive consideration, offerors must provide in their proposals:

(1) The name(s) and contact information of the VIP-listed SDVOSB(s)/VOSB(s) with whom they intend to team or subcontract.

(2) A brief description of the proposed team or subcontractor(s) arrangement.

(3) The approximate dollar value of the proposed teaming arrangements or subcontract(s).

(4) Evidence of teaming partner/subcontractor's VIP database registration and verification.

(e) Pursuant to 38 U.S.C. 8127(g), any business concern that is determined by VA to have willfully and intentionally misrepresented a company's SDVOSB/VOSB status is subject to debarment for a period of not less than five years. This includes the debarment of all principals in the business.

(End of clause)

852.208-71 Service-Disabled Veteran-Owned and Veteran-Owned Small Business Evaluation Factor Commitments - Orders and BPAs.

As prescribed in 808.405-570, insert the following clause:

Service-Disabled Veteran-Owned and Veteran-Owned Small Business Evaluation Factor Commitments - Orders and BPAs (Nov 2022)

(a) The Contractor agrees, if selected on the basis of service-disabled veteran-owned small business (SDVOSB) or veteran-owned small business (VOSB) status, to comply with the eligibility requirements in subpart 819.70, including the limitation on subcontracting requirements at 13 CFR 125.6.

(b) The Contractor agrees, if selected for award on the basis of teaming/subcontracting in accordance with 852.208-70, Service-Disabled Veteran-Owned and Veteran-Owned Small Business Evaluation Factors - Orders and BPAs, to use the evaluated firm(s) as proposed or if approved by contracting officer to substitute one or more VIP-verified SDVOSB/VOSB for work of the same or similar value.

(c) Pursuant to 38 U.S.C. 8127(g), any business concern that is determined by VA to have willfully and intentionally misrepresented a company's SDVOSB/VOSB status is subject to debarment for a period of not less than five years. This includes the debarment of all principals in the business.

(End of clause)

852.209-70 Organizational Conflicts of Interest.

As prescribed in 809.507-1(b), insert the following provision:

Organizational Conflicts of Interest (OCT 2020)

(a) It is in the best interest of the Government to avoid situations which might create an organizational conflict of interest or where the Offeror's performance of work under the contract may provide the Contractor with an unfair competitive advantage. The term “organizational conflict of interest” means that because of other activities or relationships with other persons, a person is unable to render impartial assistance or advice to the Government, or the person's objectivity in performing the contract work is or might be otherwise impaired, or the person has an unfair competitive advantage.

(b) The Offeror shall provide a statement with its offer which describes, in a concise manner, all relevant facts concerning any past, present, or currently planned interest (financial, contractual, organizational, or otherwise) or actual or potential organizational conflicts of interest relating to the services to be provided under this solicitation. The Offeror shall also provide statements with its offer containing the same information for any consultants and subcontractors identified in its proposal and which will provide services under the solicitation. The Offeror may also provide relevant facts that show how its organizational and/or management system or other actions would avoid or mitigate any actual or potential organizational conflicts of interest.

(c) Based on this information and any other information solicited or obtained by the Contracting Officer, the Contracting Officer may determine that an organizational conflict of interest exists which would warrant disqualifying the Contractor for award of the contract unless the organizational conflict of interest can be mitigated to the Contracting Officer's satisfaction by negotiating terms and conditions of the contract to that effect. If the conflict of interest cannot be mitigated and if the Contracting Officer finds that it is in the best interest of the United States to award the contract, the Contracting Officer shall request a waiver in accordance with FAR 9.503.

(d) Nondisclosure or misrepresentation of actual or potential organizational conflicts of interest at the time of the offer or arising as a result of a modification to the contract, may result in the termination of the contract at no expense to the Government.

(End of Provision)

852.211-70 Equipment Operation and Maintenance Manuals.

As prescribed in 811.107-70, insert the following clause:

Equipment Operation and Maintenance Manuals (NOV 2018)

The Contractor shall follow standard commercial practices to furnish manual(s), handbook(s) or brochure(s) containing operation, installation, and maintenance instructions, including pictures or illustrations, schematics, and complete repair/test guides, as necessary, for technical medical equipment and devices, and/or other technical and mechanical equipment provided per CLIN(s) #______ [Contracting Officer insert CLIN information]. The manuals, handbooks or brochures shall be provided in hard copy, soft copy or with electronic access instructions, consistent with standard industry practices for the equipment or device. Where applicable, the manuals, handbooks or brochures will include electrical data and connection diagrams for all utilities. The documentation shall also contain a complete list of all replaceable parts showing part number, name, and quantity required.

(End of clause)

852.211-71 [Reserved]

852.211-72 Technical Industry Standards.

As prescribed in 811.204-70, insert the following clause:

Technical Industry Standards (NOV 2018)

(a) The Contractor shall conform to the standards established by:______ [Contracting Officer: Insert name of organization establishing the requirement, reference title, cite and date, e.g., United States Department of Agriculture (USDA), Institutional Meat Purchase Specifications (IMPS), Series 100, Beef products, Jan 2010] as to [Contracting Officer: Insert item and CLIN, e.g., CLIN 0005 Ground Beef].

(b) The Contractor shall submit proof of conformance to the standard. This proof may be a label or seal affixed to the equipment or supplies, warranting that the item(s) have been tested in accordance with the standards and meet the contract requirement. Proof may also be furnished by the organization listed above certifying that the item(s) furnished have been tested in accordance with and conform to the specified standards.

(c) Offerors may obtain the standards cited in this provision by submitting a request, including the solicitation number, title and number of the publication to: [Organization]__________ [Mail or email address] __________.

(d) The offeror shall contact the Contracting Officer if response is not received within two weeks of the request.

(End of clause)

852.211-73--852.211-75 [Reserved]

852.211-76 Liquidated Damages - Reimbursement for Data Breach Costs.

As prescribed in 811.503-70, insert the following clause:

Liquidated Damages - Reimbursement for Data Breach Costs (FEB 2023)

(a) Definition. As used in this clause, “contract” means any contract, agreement, order or other instrument and encompasses the definition set forth in FAR 2.101.

(b) Non-disclosure requirements. As a condition of performance under a contract, order, agreement, or other instrument that requires access to sensitive personal information as defined in VAAR 802.101, the following is expressly required -

(1) The Contractor, subcontractor, their employees or business associates shall not, directly or through an affiliate or employee of the Contractor, subcontractor, or business associate, disclose sensitive personal information to any other person unless the disclosure is lawful and is expressly permitted under the contract; and

(2) The Contractor, subcontractor, their employees or business associates shall immediately notify the Contracting Officer and the Contracting Officer's Representative (COR) of any security incident that occurs involving sensitive personal information.

(c) Liquidated damages. If the Contractor or any of its agents fails to protect VA sensitive personal information or otherwise engages in conduct which results in a data breach, the Contractor shall, in place of actual damages, pay to the Government liquidated damages of __ [Contracting Officer insert amount] per affected individual in order to cover costs related to the notification, data breach analysis and credit monitoring. In the event the Contractor provides payment of actual damages in an amount determined to be adequate by the Contracting Officer, the Contracting Officer may forgo collection of liquidated damages.

(d) Purpose of liquidated damages. Based on the results from VA's determination that there was a data breach caused by Contractor's or any of its agents' failure to protect or otherwise engaging in conduct to cause a data breach of VA sensitive personal information, and as directed by the Contracting Officer, the Contractor shall be responsible for paying to the VA liquidated damages in the amount of __ [Contracting Officer insert amount] per affected individual to cover the cost of the following:

(1) Notification related costs.

(2) Credit monitoring reports.

(3) Data breach analysis and impact.

(4) Fraud alerts.

(5) Identity theft insurance.

(e) Relationship to termination clause, if applicable. If the Government terminates this contract, purchase order, or agreement, in whole or in part under clause 52.249-8, Default - Fixed-Price Supply and Service, or any other related FAR or VAAR clause included in the contract, in addition to the required liquidated damages for data breach-related expenses specified in paragraph (c) above, the Contractor is liable for excess costs for those supplies and services for repurchase as may be required under the Termination clause.

(End of clause)

Alternate I (FEB 2023). In commercial products or commercial services acquisitions awarded under the procedures of FAR part 8 or 12, substitute this paragraph (e) in lieu of paragraph (e) in the basic clause:

(e) Relationship to termination clause, if applicable. If the Government terminates this contract in whole or in part under the Termination for cause paragraph, FAR 52.212-4(m), Contract Terms and Conditions - Commercial Products and Commercial Services, the Contractor is liable for damages accruing until the Government reasonably obtains delivery or performance of similar supplies or services. These damages are in addition to costs of repurchase as may be required under the Termination clause.

Alternate II (FEB 2023). In simplified acquisitions exceeding the micro-purchase threshold that are for other than commercial products or commercial services awarded under the procedures of FAR part 13 (see FAR 13.302-5(d)(1) and the clause at FAR 52.213-4), substitute this paragraph (e) in lieu of paragraph (e) in the basic clause:

(e) Relationship to termination clause, if applicable. If the Government terminates this contract in whole or in part under the Termination for cause paragraph, FAR 52.213-4(g), Terms and Conditions - Simplified Acquisitions (Other Than Commercial Products and Commercial Services), or any other applicable FAR or VAAR clause, the Contractor is liable for damages accruing until the Government reasonably obtains delivery or performance of similar supplies or services. These damages are in addition to costs of repurchase as may be required under the Termination clause.

852.212-70 [Reserved]

852.212-71 Gray Market and Counterfeit Items.

As prescribed in 812.301(f), insert the following clause:

Gray Market and Counterfeit Items (FEB 2023)

(a) No used, refurbished, or remanufactured supplies or equipment/parts shall be provided. This procurement is for new Original Equipment Manufacturer (OEM) items only. No gray market items shall be provided. Gray market items are OEM goods intentionally or unintentionally sold outside an authorized sales territory or sold by non-authorized dealers in an authorized sales territory.

(b) No counterfeit supplies or equipment/parts shall be provided. Counterfeit items include unlawful or unauthorized reproductions, substitutions, or alterations that have been mismarked, misidentified, or otherwise misrepresented to be an authentic, unmodified item from the original manufacturer, or a source with the express written authority of the original manufacturer or current design activity, including an authorized aftermarket manufacturer. Unlawful or unauthorized substitutions include used items represented as new, or the false identification of grade, serial number, lot number, date code, or performance characteristics.

(c) Vendor shall be an OEM, authorized dealer, authorized distributor, or authorized reseller for the proposed equipment/system, verified by an authorization letter or other documents from the OEM. All software licensing, warranty and service associated with the equipment/system shall be in accordance with the OEM terms and conditions.

(End of clause)

852.212-72 Gray Market and Counterfeit Items - Information Technology Maintenance Allowing Other-than-New Parts.

As prescribed in 812.301(f), insert the following clause:

Gray Market and Counterfeit Items - Information Technology Maintenance Allowing Other-Than-New Parts (FEB 2023)

(a) Used, refurbished, or remanufactured parts may be provided. No gray market supplies or equipment shall be provided. Gray market items are Original Equipment Manufacturer (OEM) goods intentionally or unintentionally sold outside an authorized sales territory or sold by non-authorized dealers in an authorized sales territory.

(b) No counterfeit supplies or equipment shall be provided. Counterfeit items include unlawful or unauthorized reproductions, substitutions, or alterations that have been mismarked, misidentified, or otherwise misrepresented to be an authentic, unmodified item from the original manufacturer, or a source with the express written authority of the original manufacturer or current design activity, including an authorized aftermarket manufacturer. Unlawful or unauthorized substitutions include used items represented as new, or the false identification of grade, serial number, lot number, date code, or performance characteristics.

(c) Vendor shall be an OEM, authorized dealer, authorized distributor or authorized reseller for the proposed equipment/system, verified by an authorization letter or other documents from the OEM. All software licensing, warranty and service associated with the equipment/system shall be in accordance with the OEM terms and conditions.

(End of clause)

852.214-70 [Reserved]

852.214-71 Restrictions on Alternate Item(s).

As prescribed in 814.201-6(a)(1), insert the following provision:

Restrictions on Alternate Item(s) (MAY 2018)

Bids on [ ]* will be considered only if acceptable bids on [ ]** are not received or do not satisfy the total requirement.

*Contracting Officer will insert an alternate item that is considered acceptable.

**Contracting Officer will insert the required item and item number.

(End of provision)

852.214-72 Alternate Item(s).

As prescribed in 814.201-6(a)(2), insert the following provision:

Alternate Item(s) (MAY 2018)

Bids on [ ]* will be given equal consideration along with bids on [ ]** and any such bids received may be accepted if to the advantage of the Government. Tie bids will be decided in favor of [ ].**

*Contracting Officer will insert an alternate item that is considered acceptable.

**Contracting Officer will insert the required item and item number.

(End of provision)

852.214-73 Alternate Packaging and Packing.

As prescribed in 814.201-6(a)(3), insert the following provision:

Alternate Packaging and Packing (MAY 2018)

The bidders offer must clearly indicate the quantity, package size, unit, or other different feature upon which the quote is made. Evaluation of the alternate or multiple alternates will be made on a common denominator such as per ounce, per pound, etc., basis.

(End of provision)

852.214-74 Marking of Bid Samples.

As prescribed in 814.201-6(b), insert the following provision:

Marking of Bid Samples (MAY 2018)

Any bid sample(s) furnished must be in the quantities specified in the solicitation. Cases or packages must be plainly marked `Bid Sample(s)” with the complete lettering/numbering and description of the related bid item(s), the number of the Invitation for Bids, and the name of the bidder submitting the bid sample(s).

(End of provision)

852.215-70 Service-Disabled Veteran-Owned and Veteran-Owned Small Business Evaluation Factors.

As prescribed in 815.304-71(a), insert the following clause:

Service-Disabled Veteran-Owned and Veteran-Owned Small Business Evaluation Factors (OCT 2019)

(a) In an effort to achieve socioeconomic small business goals, VA shall evaluate offerors based on their service-disabled veteran-owned or veteran-owned small business status and their proposed use of eligible service-disabled veteran-owned small businesses (SDVOSBs) and veteran-owned small businesses (VOSBs) as subcontractors.

(b) Eligible service-disabled veteran-owned small businesses offerors will receive full credit, and offerors qualifying as veteran-owned small businesses will receive partial credit for the Service-Disabled Veteran-Owned and Veteran-Owned Small Business Status evaluation factor. To receive credit, an offeror must be registered and verified in the Vendor Information Pages (VIP) database.

(c) Non-Veteran offerors proposing to use SDVOSBs or VOSBs as subcontractors will receive some consideration under this evaluation factor. Offerors must state in their proposals the names of the SDVOSBs and VOSBs with whom they intend to subcontract and provide a brief description of the proposed subcontracts and the approximate dollar values of the proposed subcontracts. In addition, the proposed subcontractors must be registered and verified in the VIP database.

(d) Pursuant to 38 U.S.C. 8127(g), any business concern that is determined by VA to have willfully and intentionally misrepresented a company's SDVOSB/VOSB status is subject to debarment for a period of not less than five years. This includes the debarment of all principals in the business.

(End of clause)

852.215-71 Evaluation Factor Commitments.

As prescribed in 815.304-71(b), insert the following clause:

Evaluation Factor Commitments (OCT 2019)

(a) The offeror agrees, if awarded a contract, to use the service-disabled veteran-owned small businesses (SDVOSBs) or veteran-owned small businesses (VOSBs) proposed as subcontractors in accordance with 852.215-70, Service-Disabled Veteran-Owned and Veteran-Owned Small Business Evaluation Factors, or to substitute one or more SDVOSBs or VOSBs for subcontract work of the same or similar value.

(b) Pursuant to 38 U.S.C. 8127(g), any business concern that is determined by VA to have willfully and intentionally misrepresented a company's SDVOSB/VOSB status is subject to debarment for a period of not less than five years. This includes the debarment of all principals in the business.

(End of clause)

852.215-72 Notice of Intent to Re-Solicit.

As prescribed at 815.370-5, use the following provision:

Notice of Intent to Re-Solicit (OCT 2019)

This solicitation provides offerors fewer than 30 days to submit proposals. In the event that only one offer is received in response to this solicitation, the Contracting Officer may cancel the solicitation and re-solicit for an additional period of at least 30 days in accordance with 815.370-2.

(End of provision)

852.216-70 [Reserved]

852.216-71 Economic Price Adjustment of Contract Price(s) Based on a Price Index.

As prescribed in 816.203-4(e)(1), insert the following clause:

Economic Price Adjustment of Contract Price(s) Based on a Price Index (MAR 2018)

(a) To the extent that contract cost increases are provided for by this economic price adjustment clause, the Contractor warrants that the prices in this contract for the base period and any option periods do not include any amount to protect against such contingent cost increases.

(b) The Base and Adjusting Indexes, for the purpose of price adjustment under this clause, shall be ______, ¹ as contained in ______, ² as published by ______. ³ All adjustments authorized under this clause shall be made by using the Base Index and Adjusting Indexes, which are published ______. ⁴

¹ The Contracting Officer shall conduct market research to determine a suitable Consumer Price Index or other independent broad-based index to use for the solicitation. For example, for medical services, an appropriate index may be the Consumer Price Index that tracks medical services.

² Specify where the Index can be found, such as in a solicitation for laboratory services, the Contracting Officer might enter “Table 1, CPI-U: U.S. City Average, by expenditure category and commodity and service group, found at http://www.bls.gov/news.release/cpi.t01.htm”.

³ Provide the information on who publishes the applicable Index used, e.g., in the example for laboratory services, “the U.S. Department of Labor”.

⁴ State how often the Index is published, such as “monthly, around the middle of the month”. Note that some Consumer Price Indexes are not published monthly. Ensure that the correct information is provided for the specific Index used.

(1) The Base Index, for the purposes of price adjustment under this clause, shall be the most recent Index published prior to the date for receipt of offers, or the due date for receipt of best and final offers if discussions were held whichever is later. The Base Index shall remain constant for the entire term of the contract, including all option periods.

(2) The Adjusting Index shall be the most recent Index published prior to the date of contract adjustment, as specified in paragraph (d) of this clause.

(c) The percentage difference between the Base Index and the Adjusting Index, rounded to the nearest .01 percent (e.g., 4.57%), will be used in calculating all adjustments to the following line items: ______. ⁵ The prices for these line items will be multiplied by the percentage increase or decrease and the resulting amount will be added to or deducted from the original line item price for that contract period (e.g., Base Year) to arrive at the new contract price for those line items from the effective date of the adjustment to the beginning of the next contract adjustment period, rounded to the same number of decimal points as the prices originally bid. Calculations for option year contract terms will be based on the prices in the schedule for those option years.

⁵ Enter the line items that will be subject to adjustment or revise this paragraph to otherwise state what prices are subject to adjustment under this clause.

(d) The dates of contract adjustment shall be ______ ⁶ and the starting dates of each option year, if not already included in these dates. The Contracting Officer shall retain a copy of the Base Index in the contract file and, on each date of adjustment specified in this paragraph (d), shall obtain a copy of the Adjusting Index. The Contracting Officer shall calculate the adjustment due and shall, within 5 business days, issue a modification to the contract adjusting the unit or contract prices, as specified in paragraph (c). The adjusted unit or contract prices shall be effective for all orders placed or services provided after the date of contract adjustment as specified in this paragraph (d) until the beginning of the next contract adjustment period. If the Contracting Officer fails to act, the Contractor shall request in writing a contract adjustment and any subsequent adjustment shall be retroactive to the applicable date of contract adjustment specified in this paragraph (d). The Contractor's entitlement to price increases for a prior contract period (base year or option year) is waived unless the Contractor's written request for an adjustment under this clause is received by the Contracting Officer no later than 30 days following the end of the base year for changes applicable to the base year, or 30 days following the end of each option year for changes applicable to that option year. The Government's right to contract decreases for prior contract periods (base year or option year) is waived unless the Contracting Officer processes a contract modification no later than 30 days following the end of the base year for changes applicable to the base year, or 30 days following the end of each option year for changes applicable to that option year.

⁶ Establish time periods for when the Contracting Officer will process adjustments. This could be “the first day of every quarter, January, April, July, and October” or “Annually on October 1st” or some other similar time periods. Since the contracting officer is responsible for initiating the change, the Contracting Officer must establish a reminder mechanism to ensure that the adjustments are accomplished within the time period specified.

(e) An example of an adjustment calculation is provided herein for informational purposes only.

(1) The original contract price or line item prices for that contract term (e.g., base year) shall be used for all calculations during that particular contract term and new calculations shall be made for each and every contract adjustment period specified in paragraph (d) during that contract term.

(2) For purposes of this example, the contract prices for the line items as specified in paragraph (c) will be adjusted by the percentage calculated as follows:

Adjusting Index for the current period

196.6

Minus the Base Index

−188.0

Equals the Index Point Change

8.6

Index Point Change Divided by the Base Index

8.6/188.0 = .0457 *

Result Multiplied by 100 Equals the Percentage Change

4.57%

(The Index Point Change Percentage)

¹

(3) For a line item with an original bid price of $25.00 and a 4.57 percent Index Point Change increase as of the first contract adjustment period, as shown above, the calculations for a new contract price for the first contract adjustment period would be as follows: $25.00 × .0457 = $1.14, $25 + $1.14 = $26.14 **. The new contract price for this line item from the beginning of that first contract adjustment period until the start of the next contract adjustment period would be $26.14 and the Contracting Officer would issue a contract modification reflecting this price change. ** The unit price adjustment shall be rounded up or down, as in paragraph (e)(1) of this clause, to match the number of decimal places in the original bid.

(4) If the Adjusting Index went down for the second adjustment period, reflecting only a 3 percent Index Point Change increase over the Base Index, the new price for this sample line item would be reduced for the second contract adjustment period from $26.14 to $25.75 as follows: $25 × .03 = $0.75, $25 + $0.75 = $25.75. Note that the calculations for the second contract adjustment period are based on the original contract price for that contract term of $25.00. The contract price for this line item is modified to reflect this new price for the second contract adjustment period.

(5) At the start of the first option year and each subsequent option year period (as well as for each contract adjustment period specified in paragraph (d) during that option year, if different), the Contracting Officer shall recalculate the contract or unit prices for that first option year based on any changes between the Adjusting Index and the Base Index, from the original contract award date to the start of the first option period, and based on the Contractor's new option year prices. Assume the Contractor's bid price for the first option year for the above sample line item was $25.50 and the calculations shown in paragraph (e)(1) of this clause at the start of the first option period reflected a 6 percent Index Point Change. The new contract price for this sample line item at the start of the first option period would be calculated as follows: $25.50 × .06 = $1.53, $25.50 + $1.53 = $27.03. The Contracting Officer would process a contract modification reflecting a revised contract price of $27.03 for the first contract adjustment period in the first option year.

(f) Price adjustments pursuant to this clause, shall be documented by a contract modification issued by the Contracting Officer, show the Base Index (see paragraph (b)(1)), the Adjusting Index, the adjusted contract prices (see paragraph (c)), the mathematical calculations used to arrive at the adjusted contract prices, and the effective date of the adjustment (see paragraph (d)).

(g) At the start of each option year, the Contracting Officer shall, within 5 days of the start of the option year period, process a contract modification adjusting the option year prices by the then current Index Point Change percentage, if any, reflecting the new adjusted prices for that first contract adjustment period in that option year.

(h) In the event that ______ ⁷ discontinues, or alters substantially, its method of calculating the Index cited herein, the parties shall mutually agree upon an appropriate substitute for determining the price adjustment described herein. If the Contracting Officer determines that the Index consistently and substantially fails to reflect market conditions, the Contracting Officer may modify the contract to specify the use of an appropriate substitute index, effective on the date the Index specified herein begins to consistently and substantially fail to reflect market conditions.

⁷ Enter in the name of the entity whose index is used in the clause. In most cases when using this clause format, the index used would be a CPI-U Index and the Contracting Officer would enter “the U.S. Department of Labor”.

(i) Any dispute arising under this clause shall be resolved subject to the “Disputes” clause of the contract.

(End of clause)

852.216-72 Proportional Economic Price Adjustment of Contract Price(s) Based on a Price Index.

As prescribed in 816.203-4(e)(2), insert the following clause:

Proportional Economic Price Adjustment of Contract Price(S) Based on a Price Index (MAR 2018)

(a) To the extent that contract cost increases are provided for by this economic price adjustment clause, the Contractor warrants that the prices in this contract for any option periods do not include any amount to protect against such contingent cost increases.

(b) The cost index, for the purpose of price adjustment under this clause, shallbe ______ ¹ as contained in ______ ² as published by ______ . ³ All adjustments authorized under this clause shall be made by using the Base Index and Adjusting Indexes, which are published ______ . ⁴

¹ The Contracting Officer shall conduct market research to determine a suitable cost index for use in the solicitation. The index used is directly related to the type of commodity or service most likely to impact the Contractor and must approximately track the economic changes affecting the Contractor's costs. For transportation services, an appropriate index might be one that tracks the price of gasoline or diesel fuel. For example, in a solicitation for ambulance services, the Contracting Officer might enter into this block “the “Weekly U.S. Retail Gasoline Prices, Regular Grade” Index for New England” (or California or whichever index is the most appropriate).

² Specify where the index can be found, such as in an example for gasoline, “the Energy Information Administration website (see VAAM M816.203-70).

³ Provide the information on who publishes the index, such as, in an example for gasoline, “the U.S. Department of Energy.”

⁴ State how often the index used is published, such as, in an example for an index for gasoline, “weekly each Monday at 5:00 p.m. (Eastern time),” or “Tuesday if Monday is a holiday.”

(1) The Base Index, for the purposes of price adjustment under this clause, shall be the most recent Index published prior to the closing date for receipt of offers, or the due date for receipt of best and final offers if discussions are held. This Base Index shall remain constant throughout the life of the contract, including all options.

(2) The Adjusting Index shall be the most recent Index published prior to the date of contract adjustment, as specified in paragraph (f).

(c) For purposes of this clause, it will be conclusively presumed that ______ percent (%) ⁵ of the price of ______ ⁶ represents the Base Cost of ______ ⁷ and the resulting Base Cost will be the basis upon which adjustment will be made under this clause. This Base Cost will be used in calculating all adjustments to the following line items: ______. ⁸ A new Base Cost will be calculated for each option year period based on the new option year prices.

⁵ Prior to issuing the solicitation, the Contracting Officer must conduct market research to determine an appropriate percentage to include in this paragraph. The percentage should reflect that portion of the unit price for the services or supplies being acquired that is applicable to the indexed commodity. For instance, in the case of an ambulance contract, research might indicate that, at the time the solicitation is being drafted and based on prior per-mile bid prices, the cost of gasoline accounts for 10% of the per mile cost of operating an ambulance. For example, if the prior bid price had been $1.60 per mile, ambulances average 10 miles per gallon, and the cost of gasoline had been $1.559 per gallon, 1 mile's worth of gasoline ($.16) would be approximately ten (10) percent of the prior per mile bid price of $1.60 per mile. This percent must be stated in the solicitation so that the same figure applies to all bidders. This figure remains constant throughout the life of the contract.

⁶ Enter in this block the portion of the contract that will be subject to price adjustment, e.g., “each one-way mile of ambulance services,” or the line items that will be subject to price adjustment.

⁷ Enter in this block the commodity applicable to the index being used, as in an example for an ambulance contract, “regular grade gasoline”.

⁸ Enter the line items that will be subject to adjustment, as in an example for an ambulance contract, the line items that reflect the one-way cost per mile for ambulance services for the base year and for each option year.

(d) The percentage of the price of the indexed commodity (see paragraph (c)) remains fixed throughout the life of the contract and is not subject to modification under this clause. Any pricing actions pursuant to the “Changes” clause or other clause or provision of the contract, except for this clause, will be priced as though there were no provisions for economic price adjustment.

(e) All price adjustments shall be applicable only to the specific contract adjustment period to which the calculations are made. For every contract adjustment period, new calculations shall be made and new prices determined. Every adjustment during the Base Year shall be based on the original contract prices for that contract year and every adjustment during an option year shall be based on the original contract prices for that option year. The Contracting Officer must make new calculations for each and every contract adjustment period specified in paragraph (f) and at the beginning of each new option year, if different.

(f) The dates of contract adjustment shall be ______ ⁹ and the starting dates of each option year, if not already included in these dates. The Contracting Officer shall retain a copy of the Base Index in the contract file and, on each date of adjustment specified herein, obtain a copy of the Adjusting Index. The Contracting Officer shall calculate the adjustment due and shall, within 5 business days, issue a modification to the contract adjusting the contract or unit price(s). The adjusted contract or unit price(s) shall be effective for all orders placed or services provided after the date of contract adjustment, as specified in this paragraph (f), until the date of the next contract adjustment. If the Contracting Officer fails to act, the Contractor shall request a contract adjustment in writing and any subsequent adjustment shall be retroactive to the applicable date of contract adjustment. The Contractor's entitlement to price increases for a prior contract period (base year or option year) shall be waived unless the Contractor's written request for an adjustment under this clause is received by the Contracting Officer no later than 30 days following the end of the base year for changes applicable to the base year, or 30 days following the end of each option year for changes applicable to that option year. The Government's right to contract decreases for prior contract periods (base year or option year) shall be waived unless the Contracting Officer processes a contract modification no later than 30 days following the end of the base year for changes applicable to the base year, or 30 days following the end of each option year for changes applicable to that option year.

⁹ Establish time periods for when the Contracting Officer will process adjustments. This could be “the first day of each month” or “the first day of every quarter, January, April, July, and October” or “annually on October 1st” or some other similar time periods. Since the Contracting Officer is responsible for initiating the change, the Contracting Officer must establish a reminder mechanism to ensure that the adjustments are accomplished on time.

(g) An example of an adjustment calculation is provided herein for informational purposes only.

(1) For purposes of this example, assume that a contract is for ambulance services, that the contract price is $2.10 per mile one way, that price adjustments will be made on the basis of the cost of gasoline, that the cost of gasoline represents 10% of the total cost per mile (the Base Cost is 10% of $2.10 (the per mile one way price in Line Item X), or $0.21), and that contract adjustments will be made quarterly. If the Base Index (the price of gasoline the week prior to receipt of bids) is $1.559 per gallon and the price of gasoline at the first date of contract adjustment is $2.129 per gallon, the calculations for contract price adjustment would be as follows:

Adjusting Index (most recent Index cost of gasoline as of the date of the first adjustment period)

$2.129 per gallon.

Minus the Base Index (Index cost of gasoline as of the date of receipt of offers)

−$1.559 per gallon.

Equals increase (or decrease) to the Base Index

$0.570.

Divide increase (or decrease) to the Base Index by the Base Index

$0.570 + $1.559 = .3656 * (36.56% increase).

Base Cost of $0.21 (10% of $2.10) multiplied by .3656 = $0.0768 unit price increase. New Unit price following the adjustment is $2.10 plus $0.0768 = $2.1768 per mile (rounded to $2.18) **

²

(2) For the second contract adjustment period, all calculations would be based on the original contract bid price for that contract year, $2.10 per mile in this example. If the price of gasoline goes down during the second adjustment period to the original Base Index price of $1.559 per gallon, the adjusted contract price for that second period would return to $2.10 per mile (there would be a zero percent increase or decrease to the Base Cost and thus no change to the original bid price for that contract adjustment period). The Contracting Officer would then issue a contract modification returning the contract price from $2.18 to $2.10 per mile for that contract adjustment period. If, on the other hand, the price of gasoline actually went below the Base Index price, say to $1.449 per gallon, the calculations for the second economic price adjustment period would be as follows:

Adjusting Index (most recent Index cost of gasoline as of the date of the second adjustment period)

$1.449 per gallon.

Minus the Base Index (Index cost of gasoline as of the date of receipt of offers)

−$1.559 per gallon.

Equals increase (or decrease) to Base Index

($0.110) (a negative $.11).

Divide increase (or decrease) to the Base Index by the Base Index

($0.11) + $1.559 = (.0706) (7.06% decrease).

Base Cost of $0.21 (10% of $2.10) multiplied by (.0706) = ($0.0148) unit price decrease

New Unit price following the second economic price adjustment is $2.10 minus $0.0148 = $2.0852 per mile (rounded to $2.09)

(3) At the start of the first option year, the Contracting Officer shall recalculate the price per mile based on any changes in the price of gasoline from the original contract award date and based on the Contractor's new first option year price per mile. Assuming the Contractor's bid price per mile for the first option year was $2.25 per mile, the new Base Cost for gasoline would be 10% of $2.25, or $0.225 (note that the original percent figure from paragraph (c) (10% in this sample) stays constant throughout the life of the contract), but the Base Cost would change if the option year contract price changes. If the Adjusting Index for gasoline at the start of the first option year was now up to $1.899 per gallon, the new first option year price for the first contract adjustment period would be calculated as follows:

Adjusting Index (most recent Index cost of gasoline as of the first day of the first option period)

$1.899 per gallon.

Minus the Base Index (Index cost of gasoline as of the date of receipt of offers)

−$1.559 per gallon.

Equals increase (or decrease) to the Base Index

$0.340.

Divide the increase (or decrease) to the Base Index by the Base Index

$0.34 + $1.559 = .2181 (21.81% increase).

Base Cost of $0.225 (10%* of $2.25) multiplied by .2181 = $0.0491 unit price increase

New Unit price for the first contract adjustment period in the first option year is $2.25 plus $0.0491 = $2.2991 per mile (rounded to $2.30 per mile).

³

(h) Price adjustments pursuant to this clause, which shall be made by contract modification issued by the Contracting Officer, shall show the Base Index (see paragraph (b)(1)), the Adjusting Index, the Base Cost (see paragraph (c)), the mathematical calculations used to arrive at the adjusted contract unit price, and the effective date of the adjustment.

(i) In the event that ______ ¹⁰ discontinues, or alters substantially, its method of calculating the Index cited herein, the parties shall mutually agree upon an appropriate substitute for determining the price adjustment described herein. If the Contracting Officer determines that the Index consistently and substantially fails to reflect market conditions, the Contracting Officer may modify the contract to specify use of an appropriate substitute index, effective on the date the Index specified herein begins to consistently and substantially fail to reflect market conditions.

¹⁰ Enter in the name of the entity whose index is used in the clause. In the example for ambulance services using the “Weekly U.S. Retail Gasoline Prices, Regular Grade” index; the Contracting Officer would enter the “Energy Information Administration, Department of Energy”.

(j) Any dispute arising under this clause shall subject to the “Disputes” clause of the contract.

(End of clause)

852.216-73 Economic Price Adjustment - State Nursing Home Care for Veterans.

As prescribed in 816.203-4(e)(3), insert the following clause:

Economic Price Adjustment - State Nursing Home Care for Veterans (MAR 2018)

This clause does not apply to rates for non-Medicaid nursing homes.

(a) Rate Determination. The per diem rate is established by the current Medicaid rate for Medicaid approved nursing home care plus a fair market amount (percentage) to cover the costs of supplies, services, and equipment above that provided under Medicaid established by the local State Medicaid Agency (SMA). Rates established after the effective date of this contract will require a modification to the contract by the Contacting Officer.

(1) The Medicaid rate covers room, board, and routine nursing care services.

(2) For all levels of nursing care a percentage is added for routine ancillary services/supplies, such as drugs, nursing supplies, oxygen (occasional use), x-ray, laboratory, physician visits, and rental equipment.

(3) Special equipment, e.g. Clinitron bed, is not considered routine ancillary services (and may not be provided by the VA).

(4) Drug costs which comprise more than eight and one-half percent (8.5%) of the per diem rate are generally not considered routine ancillary supplies (and may not be provided by the VA).

(5) Rehabilitation therapies will be provided as distinct levels of care, i.e., skilled, intermediate, and custodial care. Hospice Care and Dialysis are not included in the rate. Payment for Hospices and Dialysis services is provided by the VA or other payers as determined by the Veteran with the VA's approval.

(b) Economic Price Adjustment. This clause does not apply to ancillary services that may be added or deleted from the agreement.

(1) The per diem rate(s) will apply throughout the term of this contract, including extension period(s). The rate(s) may be adjusted only to reflect a change in a Medicaid rate as authorized by the SMA. Normally, this will be on an annual basis. The negotiated percentage above the Medicaid rate, to cover the all-inclusive nature of the contract, will not be renegotiated; but will be applied and added to the new Medicaid rate for the adjusted per diem rate for each level of care item. In this regard, new rates will be negotiated requiring a modification to the contact. Each per diem price adjustment under this clause is subject to the following limitations:

(2) Any adjustment shall be limited to the effect of increases or decreases in the approved SMA's patient care components within the affected Medicaid groups.

(3) Adjustments will occur no more frequently than those issued by the SMA.

(4) No adjustments are made until the Contracting Officer receives from the SMA an authenticated copy of the new rates signed and dated at the top right of the document by the authorized nursing home official. Within ten days after this occurs, the Contracting Officer will execute an approval signature and date at the approximate locations of the nursing home official's signature, the action of which will serve as the effective date of the adjusted rate. A copy of the fully executed document will be sent to the nursing home official for record keeping purposes.

(End of clause)

852.216-74 Economic Rice Adjustment - Medicaid Labor Rates.

As prescribed in 816.203-4(e)(4), insert the following clause:

Economic Price Adjustment - Medicaid Labor Rates (MAR 2018)

This clause does not apply to rates for non-Medicaid nursing homes.

(a) The Contractor shall notify the Contracting Officer if, at any time during contract performance, the Medicaid rate set by the State Medicaid Agency (SMA) for contract line item increases or decreases in the Schedule. The Contractor shall furnish this notice within 60 days after the increase or decrease, or within any additional period that the Contracting Officer may approve in writing, but not later than the date of final payment under this contract. The notice shall include the Contractor's proposal for an adjustment in the contract unit prices to be negotiated under paragraph (b) of this clause, and shall include, in the form required by the Contracting Officer, supporting data explaining the cause, effective date, and the amount of the increase or decrease and the amount of the Contractor's adjustment proposal.

(b) The Contracting Officer and the Contractor shall negotiate a price adjustment to the contract's unit prices and its effective date upon receipt of the notice and data under paragraph (a) of this clause. However, the Contracting Officer may postpone the negotiations until an accumulation of increases and decreases of the Medicaid labor rates (including fringe benefits) shown in the Schedule results in an adjustment allowable under paragraph (c)(3) of this clause. The Contracting Officer shall modify this contract as follows:

(1) Include the price adjustment and its effective date;

(2) Revise the Medicaid labor rates (including fringe benefits) as shown in the Schedule to reflect the increases or decreases resulting from the SMA adjustment. The Contractor shall continue performance pending agreement on, or determination of, any adjustment and its effective date.

(c) Any price adjustment under this clause is subject to the following limitations:

(1) Adjustment shall be limited to the effect on unit prices of the increases or decreases of the Medicaid rates of pay for labor (including fringe benefits) shown in the Schedule. There shall be no adjustment for changes in rates or unit prices other than those shown in the Schedule.

(2) No upward adjustment shall apply to supplies or services that are required to be delivered or performed before the effective date of the adjustment, unless the Contractor's failure to deliver or perform according to the delivery schedule results from causes beyond the Contractor's control and without its fault or negligence, within the meaning of the Default clause.

(3) There shall be no adjustment for any change in rates of pay for labor (including fringe benefits) or unit prices for material which would not result in a net change of at least three percent of the then-current total contract price. This limitation shall not apply, however, if, after final delivery of all contract line items, either party requests an adjustment under paragraph (b) of this clause.

(4) The aggregate of the increases in any contract unit price made under this clause shall not exceed 10 percent of the original unit price. There is no percentage limitation on the amount of decreases made under this clause.

(d) The Contracting Officer, precluding certified cost and pricing data may examine the Contractor's books, records, and other supporting data relevant to the cost of labor (including fringe benefits) and material during all reasonable times until the end of 3 years after the date of final payment under this contract or the time periods specified in Subpart 4.7 of the Federal Acquisition Regulation (FAR), whichever is earlier.

(End of clause)

852.216-75 Economic Price Adjustment - Fuel Surcharge.

As prescribed in 816.203-4(e)(5), insert the following clause:

Economic Price Adjustment - Fuel Surcharge (NOV 2021)

(a) To the extent that contract fuel cost increases are provided for by this economic price adjustment clause, the Contractor warrants that the prices in this contract for any option periods do not include any amount to protect against such contingent fuel cost increases.

(b) The fuel cost index, for the purpose of price adjustment under this clause, shall be the “Weekly Retail On-Highway Diesel Prices Index.”

The Base Fuel Cost, for the purpose of price adjustments under this clause, shall be the most recent Index Weekly Average Diesel Fuel Price per gallon published prior to the closing date for receipt of offers, or the due date for receipt of final proposal revisions if discussions are held.

(c) For purposes of this clause, it will be conclusively presumed that x% increase or decrease of the Base Fuel Cost represents a reasonable fluctuation of diesel fuel prices. The Base Fuel Cost (±) x% price range will be determined for the base contract year and will remain constant throughout the life of the contract, including option years. Base Fuel Cost price range is documented at time of contract award.

(d) Increases (or decreases) in the diesel fuel costs (Base Fuel Cost x%) as listed on the Index two weeks prior to the end of each calendar quarter can trigger a request from the Contractor to the Government (or from the Government to the Contractor) for cost adjustments. Notice must be in writing to the Subsistence Prime Vendor (SPV) Contracting Officer (or Contracting Officer's Representative) no less than ten days prior to the beginning of the next quarter.

(e) Since fuel cost is only a part of the SPV Contracted distribution cost, the adjustment will be made as a penny per delivered case for every ten cent fuel price per gallon increase or decrease to the Base Fuel Cost x%. The difference is rounded down to the nearest whole cent and will be added to last line of each invoice noted as “Fuel Adjustment”.

Example calculation of fuel price change:

Price $2.50 Base (+ or −) 15% Average National Diesel Fuel $2.88−$2.13.

3rd QTR (3rd week June) first year. Fuel Price $3.05 Calculation:

$3.05−2.88 = $.17 (rounded down to 10 cents) Add one cent per delivered case to each invoice, starting first Monday of July.

3rd QTR Diesel Fuel Price decrease

$2.13−1.80 = $ .33 (rounded down to $.30 cents) Credit each invoice.

$1.80 Calculation:

$.03 cents per delivered case.

(f) Once approved, the date for contract fuel price adjustment will be the first Monday of the first month of each quarter unless otherwise designated at time of contract award.

(g) The Contracting Officer shall retain a copy of the Base Fuel Index establishing the Base Fuel Cost and the calculation of the price range incorporating the (±) x% adjustment in the contract file. All subsequent changes will be documented within the contract file and communicated to the Contractor and VA SPV customers via email one week prior to the fuel price adjustment implementation.

(h) Any adjustments for fuel price changes will only be implemented if requested in writing, reviewed by both parties, and provided within the designated time frames. No retroactive cost adjustments will be made. A contract modification will be issued at inception of first increase or decrease detailing Base Fuel Cost, price range, and calculation of first fuel adjustment charge. Adjustment will remain in effect with quarterly calculation changes as needed until price falls within Base Fuel Cost price range. A contract modification will be issued to terminate the adjustment when price returns to Base Fuel Cost (±) x% price range.

(i) In the event that “the Energy Information Administration, Department of Energy” discontinues, or substantially alters its method of calculating the national average diesel fuel prices cited herein, the parties shall mutually agree upon an appropriate substitute for determining the price adjustment described herein. If the Contracting Officer determines the Index consistently and substantially fails to reflect market conditions, the Contracting Officer may modify the contract to specify use of an appropriate substitute Index, effective on the date the Index specified herein begins to consistently and substantially fail to reflect market conditions.

(j) Any dispute arising under this clause shall be determined in accordance with and subject to the “Disputes” clause of the contract.

(End of clause)

852.216-76 Requirements - Supplement for Mortuary Services.

As prescribed in 816.506-70, insert the following clause:

Requirements - Supplement for Mortuary Services (OCT 2019)

(a) Except as provided in paragraphs (c) and (d) of this clause, the Government will order from the Contractor all of its requirements in the area of performance for the supplies and services listed in the schedule of this contract.

(b) Each order will be issued as a delivery order and will list -

(1) The supplies or services being ordered;

(2) The quantities to be furnished;

(3) Delivery or performance dates;

(4) Place of delivery or performance;

(5) Packing and shipping instructions;

(6) The address to send invoices; and

(7) The funds from which payment will be made.

(c) The Government may elect not to order supplies and services under this contract in instances where the body is removed from the area for medical, scientific, or other reason.

(d) In an epidemic or other emergency, the contracting activity may obtain services beyond the capacity of the Contractor's facilities from other sources.

(e) Contracting Officers of the following activities may order services and supplies under this contract:

(End of clause)

852.217-70 Contract Action Definitization.

As prescribed in 817.7005(a), insert the following clause:

Contract Action Definitization (JUL 2019)

(a) A [Insert specific type of contract action] is contemplated. The Contractor agrees to begin promptly negotiating with the Contracting Officer the terms of a definitive contract action that will include all clauses required by the Federal Acquisition Regulation (FAR) on the date of execution of the undefinitized contract action, all clauses required by law on the date of execution of the definitive contract action, and any other mutually agreeable clauses, terms, and conditions. The Contractor agrees to submit a ______ [Insert type of proposal, e.g. , fixed-price, or cost-and-fee] proposal with cost or pricing data, as appropriate, supporting it.

(b) The schedule for definitizing this contract action is as follows [Insert target date for definitization of the contract action and dates for submission of proposal, beginning of negotiations, and, if appropriate, submission of the make-or-buy plans, subcontracting plans, and cost or pricing data].

(c) If agreement on a definitive contract action to supersede this undefinitized contract action is not reached by the target date in paragraph (b) of this clause, or within any extension of it granted by the Contracting Officer, the Contracting Officer may, with the approval of a Contracting Officer one level above, determine a reasonable price or fee in accordance with FAR subpart 15.4 and FAR part 31, subject to Contractor appeal as provided in the Disputes clause. In any event, the Contractor shall proceed with completion of the contract, subject only to FAR 52.216-24, Limitation of Government Liability.

(1) After the Contracting Officer's determination of price or fee, the contract shall be governed by -

(i) All clauses required by the FAR on the date of execution of this undefinitized contract action for either fixed-price or cost-reimbursement contracts, as determined by the Contracting Officer under this paragraph (c);

(ii) All clauses required by law as of the date of the Contracting Officer's determination; and

(iii) Any other clauses, terms, and conditions mutually agreed upon.

(2) To the extent consistent with paragraph (c)(1) of this clause, all clauses, terms, and conditions included in this undefinitized contract action shall continue in effect, except those that by their nature apply only to an undefinitized contract action.

(d) The definitive contract action resulting from this undefinitized contract action will include a negotiated ________ [Insert “cost/price ceiling” or “firm-fixed-price”] in no event to exceed ________ [Insert the not-to-exceed amount].)

(End of clauspe

852.219-70 VA Small Business Subcontracting Plan Minimum Requirements.

As prescribed in 819.708, insert the following clause:

VA Small Business Subcontracting Plan Minimum Requirements (NOV 2022)

(a) This clause does not apply to small business concerns.

(b) If the offeror is required to submit an individual subcontracting plan, the minimum goals for award of subcontracts to VA verified service-disabled veteran-owned small business and veteran-owned small business SDVOSB/VOSB shall be at least commensurate with the Department's annual SDVOSB/VOSB subcontracting goals.

(c) For a commercial plan, the minimum goals for award of subcontracts to SDVOSB/VOSB shall be at least commensurate with the Department's annual service-disabled veteran-owned small business and veteran-owned small business subcontracting goals for the total value of projected subcontracts to support the sales for the commercial plan.

(d) To be credited toward goal achievements, SDVOSB/VOSBs must be verified as eligible in the VA's Vendor Information Pages (VIP) database at https://www.vetbiz.va.gov/vip/. A contractor may reasonably rely on a subcontractor's status as shown in the VIP database as of the date of subcontract award, provided the contractor retains records of the results of the VIP database query.

(e) The Contractor shall annually submit a listing of SDVOSB/VOSB (for which credit toward goal achievement is to be applied) for review by personnel in the Office of Small and Disadvantaged Business Utilization. Use VA Form 0896A, Report of Subcontracts to Small and Veteran-Owned Business.

(f) Pursuant to 38 U.S.C. 8127(g), any business concern that is determined by VA to have willfully and intentionally misrepresented a company's SDVOSB/VOSB status is subject to debarment for a period of not less than five years. This includes the debarment of all principals in the business.

(End of clause)

852.219-71 Notification of Competition Limited to Eligible 8(a) Participants.

As prescribed in 819.811-370, when FAR 52.219-18, Notification of Competition Limited to Eligible 8(a) Participants, is utilized, use this clause in conjunction with the FAR clause.

Notification of Competition Limited to Eligible 8(A) Participants (NOV 2022)

Substitute paragraph (c) in FAR Clause 52.219-18 as follows:

(c) Any award resulting from this solicitation will be made directly by the Contracting Officer to the successful 8(a) offeror. Although SBA is not identified as such in the award form, SBA is still the Prime Contractor. Contractor shall comply with the limitations on subcontracting as provided in 13 CFR 125.6 and other 8(a) program requirements, as set forth in 13 CFR part 124.

(End of clause)

852.219-72 Notification of Section 8(a) Direct Award.

As prescribed in 819.811-370, paragraph (a), insert the following clause:

Notification of Section 8(a) Direct Award (NOV 2022)

(a) Offers are solicited only from small business concerns expressly certified by the Small Business Administration (SBA) for participation in the SBA's 8(a) Program. By submission of its offer, the Offeror represents that it is in good standing and that it meets all of the criteria for participation in the program in accordance with 13 CFR part 124.

(b) Any award resulting from this solicitation will be made directly by the Contracting Officer to the successful 8(a) offeror. Although SBA is not identified as such in the award form, SBA is still the Prime Contractor.

(c) This contract is issued as a direct award between the contracting activity and the 8(a) Contractor pursuant to the Partnership Agreement (PA) between the Small Business Administration (SBA) and the Department of Veterans Affairs.

(d) SBA retains responsibility for 8(a) certification, 8(a) eligibility determinations and related issues, and providing counseling and assistance to the 8(a) Contractor under the 8(a) program. The cognizant SBA district office is:

[To be completed by the Contracting Officer at the time of award]

(e) The contracting activity is responsible for administering the contract and taking any action on behalf of the Government under the terms and conditions of the contract. However, the contracting activity shall give advance notice to the SBA before it issues a final notice terminating performance, either in whole or in part, under the contract. The contracting activity shall obtain SBA's approval prior to processing any novation agreement(s). The contracting activity may assign contract administration functions to a contract administration office.

(f) The Contractor agrees:

(1) To notify the Contracting Officer, simultaneous with its notification to SBA (as required by SBA's 8(a) regulations), when the owner or owners upon whom 8(a) eligibility is based plan to relinquish ownership or control of the concern.

(2) Consistent with 15 U.S.C. 637(a)(21), transfer of ownership or control shall result in termination of the contract for convenience, unless SBA waives the requirement for termination prior to the actual relinquishing of ownership and control.

(3) It will adhere to the requirements of 52.219-14, Limitations of Subcontracting and other requirements in 13 CFR part 124 and 13 CFR 125.6, as applicable

(g) Any proposed joint venture involving an 8(a) Participant must be approved by SBA before contracts are awarded.

(End of clause)

852.219-73 VA Notice of Total Set-Aside for Verified Service-Disabled Veteran-Owned Small Businesses.

As prescribed in 819.7011, insert the following clause:

VA Notice Of Total set-Aside For Verified Service-Disabled Veteran-Owned Small Businesses (NOV 2022)

(a) Definition. for the Department of Veterans Affairs, “Service-disabled Veteran-owned small business concern or SDVOSB”:

(1) Means a small business concern -

(i) Not less than 51 percent of which is owned by one or more service-disabled Veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled Veterans or eligible surviving spouses (see VAAR802.101, Surviving Spouse definition);

(ii) The management and daily business operations of which are controlled by one or more service-disabled Veterans (or eligible surviving spouses) or, in the case of a service-disabled Veteran with permanent and severe disability, the spouse or permanent caregiver of such Veteran;

(iii) The business meets Federal small business size standards for the applicable North American Industry Classification System (NAICS) code identified in the solicitation document;

(iv) The business has been verified for ownership and control pursuant to 38 CFR part 74 and is listed in VA's Vendor Information Pages (VIP) database at https://www.vetbiz.va.gov/vip/; and

(v) The business will comply with VAAR subpart 819.70 and Small Business Administration (SBA) regulations regarding small business size and government contracting programs at 13 CFR parts 121 and 125, provided that any reference therein to a service-disabled veteran-owned small business concern or SDVO SBC, is to be construed to apply to a VA verified and VIP-listed SDVOSB, unless otherwise stated in this clause.

(2) The term “Service-disabled Veteran” means a Veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16).

(3) The term “small business concern” has the meaning given that term under section 3 of the Small Business Act (15 U.S.C. 632).

(4) The term “small business concern owned and controlled by Veterans with service-connected disabilities” has the meaning given the term “small business concern owned and controlled by service-disabled veterans” under section 3(q)(2) of the Small Business Act (15 U.S.C. 632(q)(2)), except that for a VA contract the firm must be listed in the VIP database (see paragraph (a)(1)(iv) of this clause).

(b) General.

(1) Offers are solicited only from VIP-listed SDVOSBs. Offers received from entities that are not VIP-listed SDVOSBs at the time of offer shall not be considered.

(2) Any award resulting from this solicitation shall be made to a VIP-listed SDVOSB who is eligible at the time of submission of offer(s) and at the time of award.

(3) The requirements in this clause apply to any contract, order or subcontract where the firm receives a benefit or preference from its designation as an SDVOSB, including set-asides, sole source awards, and evaluation preferences.

(c) Representation. Pursuant to 38 U.S.C. 8127(e), only VIP-listed SDVOSBs are considered eligible to receive award of a resulting contract. By submitting an offer, the prospective contractor represents that it is an eligible SDVOSB as defined in this clause, 38 CFR part 74, and VAAR subpart 819.70.

(d) Agreement. When awarded a contract action, including orders under multiple-award contracts, an SDVOSB agrees that in the performance of the contract, the SDVOSB shall comply with requirements in VAAR subpart 819.70 and SBA regulations on small business size and government contracting programs at 13 CFR part 121 and part 125, including the non-manufacturer rule and limitations on subcontracting requirements in 13 CFR 121.406(b) and 13 CFR 125.6. Unless otherwise stated in this clause, a requirement in 13 CFR parts 121 and 125 that applies to an SDVO SBC, is to be construed to also apply to a VIP-listed SDVOSB. For the purpose of limitations on subcontracting, only VIP-listed SDVOSBs (including independent contractors) shall be considered eligible and/or “similarly situated” (i.e., a firm that has the same small business program status as the prime contractor). An otherwise eligible firm further agrees to comply with the required certification requirements in this solicitation (see 852.219-75 or 852.219-76 as applicable). These requirements are summarized as follows:

(1) Services. In the case of a contract for services (except construction), the SDVOSB prime contractor will not pay more than 50% of the amount paid by the government to the prime for contract performance to firms that are not VIP-listed SDVOSBs (excluding direct costs to the extent they are not the principal purpose of the acquisition and the SDVOSB/VOSB does not provide the service, such as airline travel, cloud computing services, or mass media purchases). When a contract includes both services and supplies, the 50 percent limitation shall apply only to the service portion of the contract

(2) Supplies/products.

(i) In the case of a contract for supplies or products (other than from a non-manufacturer of such supplies), the SDVOSB prime contractor will not pay more than 50% of the amount paid by the government to the prime for contract performance, excluding the cost of materials, to firms that are not VIP-listed SDVOSBs. When a contract includes both supply and services, the 50 percent limitation shall apply only to the supply portion of the contract.

(ii) In the case of a contract for supplies from a non-manufacturer, the SDVOSB prime contractor will supply the product of a domestic small business manufacturer or processor, unless a waiver as described in 13 CFR 121.406(b)(5) has been granted. Refer to 13 CRF 125.6(a)(2)(ii) for guidance pertaining to multiple item procurements.

(3) General construction. In the case of a contract for general construction, the SDVOSB prime contractor will not pay more than 85% of the amount paid by the government to the prime for contract performance, excluding the cost of materials, to firms that are not VIP-listed SDVOSBs.

(4) Special trade construction contractors. In the case of a contract for special trade contractors, no more than 75% of the amount paid by the government to the prime for contract performance, excluding the cost of materials, may be paid to firms that are not VIP-listed SDVOSBs.

(5) Subcontracting. An SDVOSB must meet the NAICS size standard assigned by the prime contractor and be listed in VIP to count as similarly situated. Any work that a first tier VIP-listed SDVOSB subcontractor further subcontracts will count towards the percent of subcontract amount that cannot be exceeded. For supply or construction contracts, the cost of materials is excluded and not considered to be subcontracted. When a contract includes both services and supplies, the 50 percent limitation shall apply only to the portion of the contract with the preponderance of the expenditure upon which the assigned NAICS is based. For information and more specific requirements, refer to 13 CFR 125.6.

(e) Required limitations on subcontracting compliance measurement period. An SDVOSB shall comply with the limitations on subcontracting as follows:

[Contracting Officer check as appropriate.]

__By the end of the base term of the contract or order, and then by the end of each subsequent option period; or

__By the end of the performance period for each order issued under the contract.

(f) Joint ventures. A joint venture may be considered eligible as an SDVOSB if the joint venture is listed in VIP and complies with the requirements in 13 CFR 125.18(b), provided that any requirement therein that applies to an SDVO SBC is to be construed to apply to a VIP-listed SDVOSB. A joint venture agrees that, in the performance of the contract, the applicable percentage specified in paragraph (d) of this clause will be performed by the aggregate of the joint venture participants.

(g) Precedence. The VA Veterans First Contracting Program, as defined in VAAR 802.101, subpart 819.70, and this clause, takes precedence over any inconsistencies between the requirements of the SBA Program for SDVO SBCs, and the VA Veterans First Contracting Program.

(h) Misrepresentation. Pursuant to 38 U.S.C. 8127(g), any business concern, including all its principals, that is determined by VA to have willfully and intentionally misrepresented a company's SDVOSB status is subject to debarment from contracting with the Department for a period of not less than five years (see VAAR 809.406-2 Causes for Debarment).

(End of clause)

852.219-74 VA Notice of Total Set-Aside for Verified Veteran-Owned Small Businesses.

As prescribed in 819.7011, insert the following clause:

VA Notice of Total Set-Aside for Verified Veteran-Owned Small Businesses (NOV 2022)

(a) Definition. For the Department of Veterans Affairs, “Veteran-owned small business or VOSB”:

(1) Means a small business concern -

(i) Not less than 51 percent of which is owned by one or more Veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more Veteran(s);

(ii) The management and daily business operations of which are controlled by one or more Veteran(s);

(iii) The business meets Federal small business size standards for the applicable North American Industry Classification System (NAICS) code identified in the solicitation document;

(iv) The business has been verified for ownership and control pursuant to 38 CFR part 74 and is listed in VA's Vendor Information Pages (VIP) database at: https://www.vetbiz.va.gov/vip/; and

(v) The business will comply with VAAR subpart 819.70 and Small Business Administration (SBA) regulations regarding small business size and government contracting programs at 13 CFR parts 121 and 125, provided that any requirement therein that applies to a service-disabled veteran-owned small business concern or SDVO SBC, is to be construed to also apply to a VA verified and VIP-listed VOSB, unless otherwise stated in this clause.

(vi) The term VOSB includes VIP-listed service-disabled veteran-owned small businesses (SDVOSB).

(2) “Veteran” is defined in 38 U.S.C. 101(2).

(3) The term “small business concern” has the meaning given that term under section 3 of the Small Business Act (15 U.S.C. 632).

(4) The term “small business concern owned and controlled by Veterans” has the meaning given that term under section 3(q)(3) of the Small Business Act (15 U.S.C. 632(q)(3)), except that for a VA contract the firm must be listed in the VIP database (see paragraph (a)(1)(iv) of this clause).

(b) General.

(1) Offers are solicited only from VIP-listed VOSBs, including VIP-listed SDVOSBs. Offers received from entities that are not VIP-listed at the time of offer shall not be considered.

(2) Any award resulting from this solicitation shall be made only to a VIP-listed VOSB who is eligible at the time of submission of offer(s) and at time of award.

(3) The requirements in this clause apply to any contract, order or subcontract where the firm receives a benefit or preference from its designation as a VOSB, including set-asides, sole source awards, and evaluation preferences.

(c) Representation. Pursuant to 38 U.S.C. 8127(e), only VIP-listed VOSBs are considered eligible to receive award of a resulting contract. By submitting an offer, the prospective contractor represents that it is an eligible VOSB as defined in this clause, 38 CFR part 74, and VAAR subpart 819.70.

(d) Agreement. When awarded a contract action, including orders under multiple-award contracts, a VOSB agrees that in the performance of the contract, the VOSB shall comply with requirements in VAAR subpart 819.70 and SBA regulations on small business size and government contracting programs at 13 CFR parts 121 and 125, including the non-manufacturer rule and limitations on-subcontracting requirements in 13 CFR 121.406(b) and 125.6. Unless otherwise stated in this clause, any requirement in 13 CFR parts 121 and 125 that applies to an SDVO SBC, is to be construed to also apply to a VIP-listed VOSB. For the purpose of the limitations on subcontracting, only VIP-listed VOSB, (including independent contractors) is considered eligible and/or “similarly situated” (i.e., a firm that has the same small business program status as the prime contractor). An otherwise eligible firm further agrees to comply with the required certification requirements in this solicitation (see 852.219-75 and/or 852.219-76 as applicable). These requirements are summarized as follows:

(1) Services. In the case of a contract for services (except construction), the VOSB prime contractor will not pay more than 50% of the amount paid by the government to the prime for contract performance to firms that are not VIP-listed VOSBs (excluding direct costs to the extent they are not the principal purpose of the acquisition and the SDVOSB/VOSB does not provide the service, such as airline travel, cloud computing services, or mass media purchases). When a contract includes both services and supplies, the 50 percent limitation shall apply only to the service portion of the contract.

(2) Supplies/products.

(i) In the case of a contract for supplies or products (other than from a non-manufacturer of such supplies), the VOSB prime contractor will not pay more than 50% of the amount paid by the government to the prime for contract performance, excluding the cost of materials, to firms that are not VIP-listed VOSBs. When a contract includes both supply and services, the 50 percent limitation shall apply only to the supply portion of the contract.

(ii) In the case of a contract for supplies from a non-manufacturer, the VOSB prime contractor will supply the product of a domestic small business manufacturer or processor, unless a waiver as described in 13 CFR 121.406(b)(5) has been granted. Refer to 13 CFR 125.6(a)(2)(ii) for guidance pertaining to multiple item procurements.

(3) General construction. In the case of a contract for general construction, the VOSB prime contractor will not pay more than 85% of the amount paid by the government to the prime for contract performance, excluding the cost of materials, to firms that are not VIP-listed VOSBs.

(4) Special trade construction contractors. In the case of a contract for special trade contractors, no more than 75% of the amount paid by the government to the prime for contract performance, excluding the cost of materials, may be paid to firms that are not VIP-listed VOSBs.

(5) Subcontracting. A VOSB must meet the NAICS size standard assigned by the prime contractor and be listed in VIP to count as similarly situated. Any work that a first tier VIP-listed VOSB subcontractor further subcontracts will count towards the percent of subcontract amount that cannot be exceeded. For supply or construction contracts, the cost of materials is excluded and not considered to be subcontracted. When a contract includes both services and supplies, the 50 percent limitation shall apply only to the portion of the contract with the preponderance of the expenditure upon which the assigned NAICS is based. For information and more specific requirements, refer to 13 CFR 125.6.

(e) Required limitations on subcontracting compliance measurement period. A VOSB shall comply with the limitations on subcontracting as follows:

[Contracting Officer check as appropriate.]

__By the end of the base term of the contract or order, and then by the end of each subsequent option period; or

__By the end of the performance period for each order issued under the contract.

(f) Joint ventures. A joint venture may be considered eligible as a VOSB if the joint venture is listed in VIP and complies with the requirements in 13 CFR 125.18(b), provided that any requirement therein that applies to an SDVO SBC is to be construed to also apply to a VIP-listed VOSB. A joint venture agrees that, in the performance of the contract, the applicable percentage specified in paragraph (d) of this clause will be performed by the aggregate of the joint venture participants.

(g) Precedence. The VA Veterans First Contracting Program, as defined in VAAR 802.101, subpart 819.70, and this clause, takes precedence over any inconsistencies between the requirements of the SBA Program for SDVO SBCs and the VA Veterans First Contracting Program.

(h) Misrepresentation. Pursuant to 38 U.S.C. 8127(g), any business concern, including all its principals, that is determined by VA to have willfully and intentionally misrepresented a company's VOSB status is subject to debarment from contracting with the Department for a period of not less than five years (see VAAR 809.406-2, Causes for Debarment).

(End of clause)

852.219-75 VA Notice of Limitations on Subcontracting - Certificate of Compliance for Services and Construction.

As prescribed in 819.7011(b), insert the following clause:

VA Notice of Limitations on Subcontracting - Certificate of Compliance for Services and Construction (NOV 2022)

(a) Pursuant to 38 U.S.C. 8127(k)(2), the offeror certifies that -

(1) If awarded a contract (see FAR 2.101 definition), it will comply with the limitations on subcontracting requirement as provided in the solicitation and the resultant contract, as follows: [Contracting Officer check the appropriate box below based on the predominant NAICS code assigned to the instant acquisition as set forth in FAR 19.102.]

(i) □ Services. In the case of a contract for services (except construction), the contractor will not pay more than 50% of the amount paid by the government to it to firms that are not VIP-listed SDVOSBs as set forth in 852.219-73 or VOSBs as set forth in 852.219-74. Any work that a similarly situated VIP-listed subcontractor further subcontracts will count towards the 50% subcontract amount that cannot be exceeded. Other direct costs may be excluded to the extent they are not the principal purpose of the acquisition and small business concerns do not provide the service as set forth in 13 CFR 125.6.

(ii) □ General construction. In the case of a contract for general construction, the contractor will not pay more than 85% of the amount paid by the government to it to firms that are not VIP-listed SDVOSBs as set forth in 852.219-73or VOSBs as set forth in 852.219-74. Any work that a similarly situated VIP-listed subcontractor further subcontracts will count towards the 85% subcontract amount that cannot be exceeded. Cost of materials are excluded and not considered to be subcontracted.

(iii) □ Special trade construction contractors. In the case of a contract for special trade contractors, the contractor will not pay more than 75% of the amount paid by the government to it to firms that are not VIP-listed SDVOSBs as set forth in 852.219-73 or VOSBs as set forth in 852.219-74. Any work that a similarly situated subcontractor further subcontracts will count towards the 75% subcontract amount that cannot be exceeded. Cost of materials are excluded and not considered to be subcontracted.

(2) The offeror acknowledges that this certification concerns a matter within the jurisdiction of an Agency of the United States. The offeror further acknowledges that this certification is subject to Title 18, United States Code, Section 1001, and, as such, a false, fictitious, or fraudulent certification may render the offeror subject to criminal, civil, or administrative penalties, including prosecution.

(3) If VA determines that an SDVOSB/VOSB awarded a contract pursuant to 38 U.S.C. 8127 did not act in good faith, such SDVOSB/VOSB shall be subject to any or all of the following:

(i) Referral to the VA Suspension and Debarment Committee;

(ii) A fine under section 16(g)(1) of the Small Business Act (15 U.S.C. 645(g)(1)); and

(iii) Prosecution for violating section 1001 of title 18.

(b) The offeror represents and understands that by submission of its offer and award of a contract it may be required to provide copies of documents or records to VA that VA may review to determine whether the offeror complied with the limitations on subcontracting requirement specified in the contract. Contracting officers may, at their discretion, require the contractor to demonstrate its compliance with the limitations on subcontracting at any time during performance and upon completion of a contract if the information regarding such compliance is not already available to the contracting officer. Evidence of compliance includes, but is not limited to, invoices, copies of subcontracts, or a list of the value of tasks performed.

(c) The offeror further agrees to cooperate fully and make available any documents or records as may be required to enable VA to determine compliance with the limitations on subcontracting requirement. The offeror understands that failure to provide documents as requested by VA may result in remedial action as the Government deems appropriate.

(d) Offeror completed certification/fill-in required. The formal certification must be completed, signed and returned with the offeror's bid, quotation, or proposal. The Government will not consider offers for award from offerors that do not provide the certification, and all such responses will be deemed ineligible for evaluation and award.

Certification

I hereby certify that if awarded the contract, [insert name of offeror] will comply with the limitations on subcontracting specified in this clause and in the resultant contract. I further certify that I am authorized to execute this certification on behalf of [insert name of offeror].

Printed Name of Signee:

Printed Title of Signee:

Signature:

Date:

Company Name and Address:

(End of clause)

852.219-76 VA Notice of Limitations on Subcontracting - Certificate of Compliance for Supplies and Products.

As prescribed in 819.7011(c), insert the following clause. The contracting officer shall tailor the clause in paragraph (a)(2)(iii) as appropriate:

VA Notice of Limitations on Subcontracting - Certificate of Compliance for Supplies and Products (NOV 2022)

(a) Pursuant to 38 U.S.C. 8127(k)(2), the offeror certifies that -

(1) If awarded a contract (see FAR 2.101 definition), it will comply with the limitations on subcontracting requirement as provided in the solicitation and the resultant contract, as follows: [Offeror check the appropriate box]

(i) □ In the case of a contract for supplies or products (other than from a non-manufacturer of such supplies), it will not pay more than 50% of the amount paid by the government to it to firms that are not VIP-listed SDVOSBs as set forth in 852.219-73 or VOSBs as set forth in 852.219-74. Any work that a similarly situated VIP-listed subcontractor further subcontracts will count towards the 50% subcontract amount that cannot be exceeded. Cost of materials are excluded and not considered to be subcontracted.

(ii) □ In the case of a contract for supplies from a nonmanufacturer, it will supply the product of a domestic small business manufacturer or processor, unless a waiver as described in 13 CFR 121.406(b)(5) is granted. The offeror understands that, as provided in 13 CFR 121.406(b)(7), such a waiver has no effect on requirements external to the Small Business Act, such as the Buy American Act or the Trade Agreements Act.

(2) Manufacturer or nonmanufacturer representation and certification. [Offeror fill-in - check each applicable box below. The offeror must select the applicable provision below, identifying itself as either a manufacturer or nonmanufacturer]:

(i) □ Manufacturer or producer. The offeror certifies that it is the manufacturer or producer of the end item being procured, and the end item is manufactured or produced in the United States, in accordance with paragraph (a)(1)(i).

(ii) □ Nonmanufacturer. The offeror certifies that it qualifies as a nonmanufacturer in accordance with the requirements of 13 CFR 121.406(b) and paragraph (a)(1)(ii). The offeror further certifies it meets each element below as required in order to qualify as a nonmanufacturer. [Offeror fill-in - check each box below.]

□ The offeror certifies that it does not exceed 500 employees (or 150 employees for the Information Technology Value Added Reseller exception to NAICS code 541519, which is found at 13 CFR 121.201, footnote 18).

□ The offeror certifies that it is primarily engaged in the retail or wholesale trade and normally sells the type of item being supplied.

□ The offeror certifies that it will take ownership or possession of the item(s) with its personnel, equipment, or facilities in a manner consistent with industry practice.

(iii) □ The offeror certifies that it will supply the end item of a small business manufacturer, processor, or producer made in the United States, unless a waiver as provided in 13 CFR 121.406(b)(5) has been issued by SBA. [Contracting Officer fill-in or removal (see 13 CFR 121.1205). This requirement must be included for a single end item. However, if SBA has issued an applicable waiver of the nonmanufacturer rule for the end item, this requirement must be removed in the final solicitation or contract.]

or [Contracting officer tailor clause to remove one or other block under subparagraph (iii).]

□ If this is a multiple item acquisition, the offeror certifies that at least 50% of the estimated contract value is composed of items that are manufactured by small business concerns. [Contracting Officer fill-in or removal. See 13 CFR 121.406(d) for multiple end items. If SBA has issued an applicable nonmanufacturer rule waiver, this requirement must be removed in the final solicitation or contract.]

(3) The offeror acknowledges that this certification concerns a matter within the jurisdiction of an Agency of the United States. The offeror further acknowledges that this certification is subject to Title 18, United States Code, Section 1001, and, as such, a false, fictitious, or fraudulent certification may render the offeror subject to criminal, civil, or administrative penalties, including prosecution.

(4) If VA determines that an SDVOSB/VOSB awarded a contract pursuant to 38 U.S.C. 8127 did not act in good faith, such SDVOSB/VOSB shall be subject to any or all of the following:

(i) Referral to the VA Suspension and Debarment Committee;

(ii) A fine under section 16(g)

(1) of the Small Business Act (15 U.S.C. 645(g)(1)); and

(iii) Prosecution for violating section 1001 of title 18.

(b) The offeror represents and understands that by submission of its offer and award of a contract it may be required to provide copies of documents or records to VA that VA may review to determine whether the offeror complied with the limitations on subcontracting requirement specified in the contract or to determine whether the offeror qualifies as a manufacturer or nonmanufacturer in compliance with the limitations on subcontracting requirement. Contracting officers may, at their discretion, require the contractor to demonstrate its compliance with the limitations on subcontracting at any time during performance and upon completion of a contract if the information regarding such compliance is not already available to the contracting officer. Evidence of compliance includes, but is not limited to, invoices, copies of subcontracts, or a list of the value of tasks performed.

(c) The offeror further agrees to cooperate fully and make available any documents or records as may be required to enable VA to determine compliance. The offeror understands that failure to provide documents as requested by VA may result in remedial action as the Government deems appropriate.

(d) Offeror completed certification/fill-in required. The formal certification must be completed, signed and returned with the offeror's bid, quotation, or proposal. The Government will not consider offers for award from offerors that do not provide the certification, and all such responses will be deemed ineligible for evaluation and award.

Certification

I hereby certify that if awarded the contract, [insert name of offeror] will comply with the limitations on subcontracting specified in this clause and in the resultant contract. I further certify that I am authorized to execute this certification on behalf of [insert name of offeror].

Printed Name of Signee:

Printed Title of Signee:

Signature:

Date:

Company Name and Address:

(End of clause)

852.222-70 Contract Work-Hours and Safety Standards - Nursing Home Care for Veterans.

As prescribed in 822.305, insert the following clause:

Contract Work Hours and Safety Standards - Nursing Home Care for Veterans (MAY 2018)

(a) No Contractor and subcontractor under this contract shall prohibit the payment of overtime wages to their employees for work in excess of 40 hours in any workweek, which would otherwise be a violation of Contract Work Hours and Safety Standards (the statute) (40 U.S.C. 3701, et seq.), provided -

(1) The Contractor or subcontractor is primarily engaged in the care of nursing home patients residing on the contractor's or subcontractor's premises;

(2) There is an agreement or understanding between the Contractor or subcontractor and their employees, before performance of work, that a work period of 14 consecutive days is acceptable in lieu of a work period of 7 consecutive days for the purpose of overtime compensation;

(3) Employees receive overtime compensation at a rate no less than 1 1/2 times the employees' regular hourly rate of pay for work in excess of 80 hours in any 14 day period; and

(4) Pay is otherwise computed in accordance with the requirements of the Fair Labor Standards Act of 1938, as amended.

(b) Subcontracts. The Contractor shall insert the text of this clause, including this paragraph (b), in subcontracts at any tier. The Contractor shall be responsible for compliance by any subcontractor or lower-tier subcontractor with the provisions set forth in paragraphs (a) through (b) of this clause.

(End of clause)

852.223-70 Instructions to Offerors - Sustainable Acquisition Plan.

As prescribed in 823.103-71, when the Contracting Officer deems a Sustainable Acquisition Plan necessary, the Contracting Officer shall insert the following provision:

Instructions to Offerors - Sustainable Acquisition Plan (SEP 2019)

Offerors shall include a Sustainable Acquisition Plan in their technical proposals. The plan must describe the approach and quality assurance mechanisms for applying FAR subpart 23.1, Sustainable Acquisition Policy and other Federal laws, regulations and Executive Orders governing sustainable acquisition. The plan shall clearly identify those products and services included in the proposal.

(End of provision)

852.223-71 Safety and Health.

As prescribed by 823.303-70, the Contracting Officer shall insert the following clause:

Safety and Health (SEP 2019)

(a) To help ensure the protection of the life and health of all persons, and to help prevent damage to property, the Contractor shall comply with all Federal, State, and local laws and regulations applicable to the work being performed under this contract. These laws are implemented or enforced by the Environmental Protection Agency (EPA), Occupational Safety and Health Administration (OSHA) and other regulatory/enforcement agencies at the Federal, State, and local levels.

(1) Additionally, the Contractor shall comply with the following regulations when developing and implementing health and safety operating procedures and practices for both personnel and facilities involving the use or handling of hazardous materials and the conduct of research, development, or test projects:

(i) 29 CFR 1910.1030, Bloodborne pathogens; 29 CFR 1910.1450, Occupational exposure to hazardous chemicals in laboratories. These regulations are available at https://www.osha.gov/.

(ii) Nuclear Regulatory Commission Standards and Regulations, pursuant to the Energy Reorganization Act of 1974 (42 U.S.C. 5801 et seq.) Copies are available from the U.S. Nuclear Regulatory Commission, Washington, DC 20555-0001.

(2) The following Government guidelines are recommended for developing and implementing health and safety operating procedures and practices for both personnel and facilities:

(i) Biosafety in Microbiological and Biomedical Laboratories, Centers for Disease Control and Prevention (CDC), available at http://www.cdc.gov/biosafety/publications/index.htm.

(ii) Prudent Practices in the Laboratory, National Research Council, National Academy Press, Washington, DC 20001, available at http://www.nap.edu.

(b)

(1) The Contractor shall maintain an accurate record of, and promptly report to the Contracting Officer, all accidents or incidents resulting in the exposure of persons to toxic substances, hazardous materials; the injury or death of any person; or damage to property incidental to work performed under the contract resulting from toxic or hazardous materials and resulting in any or all violations for which the Contractor has been cited by any Federal, State or local regulatory/enforcement agency.

(2) The report shall include a copy of the notice of violation and the findings of any inquiry or inspection, and an analysis addressing the impact these violations may have on the work remaining to be performed. The report shall also state the required action(s), if any, to be taken to correct any violation(s) noted by the Federal, State, or local regulatory/enforcement agency and the time frame allowed by the agency to accomplish the necessary corrective action.

(c) If the Contractor fails or refuses to comply with the Federal, State or local regulatory/enforcement agency's directive(s) regarding any violation(s) and prescribed corrective action(s), the Contracting Officer may issue an order stopping all or part of the work until satisfactory corrective action (as approved by the Federal, State, or local regulatory/enforcement agencies) has been taken and documented to the Contracting Officer. No part of the time lost due to any such stop work order shall form the basis for a request for extension or costs or damages by the Contractor.

(d) The Contractor shall insert this clause in each subcontract involving toxic substances or hazardous materials. The Contractor is responsible for the compliance of its subcontractors with the provisions of this clause.

(End of clause)

852.228-70 Bond Premium Adjustment.

As prescribed in 828.106-70, insert the following clause:

Bond Premium Adjustment (JAN 2008)

When net changes in original contract price affect the premium of a Corporate Surety Bond by $5 or more, the Government, in determining the basis for final settlement, will provide for bond premium adjustment computed at the rate shown in the bond.

(End of clause)

852.228-71 Indemnification and Insurance.

As prescribed in 828.306, insert the following clause:

Indemnification and Insurance (MAR 2018)

(a) Indemnification. The Contractor expressly agrees to indemnify and save the Government, its officers, agents, servants, and employees harmless from and against any and all claims, loss, damage, injury, and liability, however caused, resulting from, arising out of, or in any way connected with the performance of work under this contract. Further, it is agreed that any negligence or alleged negligence of the Government, its officers, agents, servants, and employees, shall not be a bar to a claim for indemnification unless the act or omission of the Government, its officers, agents, servants, and employees is the sole, competent, and producing cause of such claims, loss, damage, injury, and liability. At the option of the Contractor, and subject to the approval by the Contracting Officer, insurance coverage may be employed as guaranty of indemnification.

(b) Insurance. Satisfactory insurance coverage is a condition precedent to award of this contract. In general, a successful bidder must present satisfactory evidence of full compliance with State and local requirements, or those below stipulated, whichever are the greater. More specifically, workers' compensation and employer's liability coverage will conform to applicable State law requirements for the service defined, whereas general liability and automobile liability of comprehensive type shall, in the absence of higher statutory minimums, be required in the amounts per vehicle used of not less than $200,000 per person and $500,000 per occurrence for bodily injury and $20,000 per occurrence for property damage. State-approved sources of insurance coverage ordinarily will be deemed acceptable to the Department of Veterans Affairs, subject to timely certifications by such sources of the types and limits of the coverages afforded by the sources to the bidder. [Contracting Officer's Note: In those instances where airplane service is to be used, substitute the word “aircraft” for “automobile” and “vehicle” and modify coverage to require aircraft public and passenger liability insurance of at least $200,000 per passenger and $500,000 per occurrence for bodily injury, other than passenger liability, and $200,000 per occurrence for property damage. Coverage for passenger liability bodily injury shall be at least $200,000 multiplied by the number of seats or passengers, whichever is greater.]

(End of clause)

852.228-72 Assisting Service-Disabled Veteran-Owned and Veteran-Owned Small businesses in Obtaining Bonds.

As prescribed in 828.106-71, insert the following clause:

Assisting Service-Disabled Veteran-Owned Small Businesses and Veteran-Owned Small Businesses in Obtaining Bonds (DEC 2009)

Prime contractors are encouraged to assist service-disabled veteran-owned and veteran-owned small business potential subcontractors in obtaining bonding, when required. Mentor firms are encouraged to assist protégé firms under VA's Mentor-Protégé Program in obtaining acceptable bid, payment, and performance bonds, when required, as a prime contractor under a solicitation or contract and in obtaining any required bonds under subcontracts.

852.228-73 Indemnification of Contractor - Hazardous Research Projects.

As prescribed in 828.7003, insert the following clause:

Indemnification of Contractor - Hazardous Research Projects (MAR 2018)

(a) This contract involves work with a risk of an unusually hazardous nature as specifically defined in the contract. The government shall indemnify the Contractor, including subcontractors of any tier, against losses or liability specified in paragraphs (b) and (c) of this clause if -

(1) The losses or liability arise out of or results from a risk defined in this contract as unusually hazardous; and

(2) The losses or liability are not covered by the financial protection required by paragraph (c).

(b) The Government shall indemnify a Contractor for -

(1) Liability (including reasonable expenses of litigation or settlement) to third persons for death, bodily injury, or loss of or damage to property from a risk that the contract defines as unusually hazardous. This indemnification shall not cover liability under State or Federal worker's injury compensation laws to employees of the Contractor who are both:

(i) Employed at the site of the contract work; and

(ii) Working on the contract for which indemnification is granted.

(2) The Government shall also indemnify the Contractor for loss of or damage to property of the Contractor from a risk that the contract defines as unusually hazardous.

(c) A Contractor shall have and maintain an amount of financial protection to cover liability to third persons and loss of or damage to the Contractor's property. Financial protection may include private insurance, private contractual indemnities, self-insurance, other proof of financial responsibility, or a combination that provides the maximum amount required. The financial protection provided must meet one of the following -

(1) The maximum amount of insurance available from private sources; or

(2) A lesser amount that the Secretary establishes after taking into consideration the cost and terms of private insurance.

(d) Actions in event of a claim -

(1) The Contractor shall notify the Contracting Officer of any claim or suit against the Contractor for death, bodily injury, or loss of or damage to property; and

(2) The Government may elect to control or assist in the defense of any suit or claim for which indemnification is provided in the contract.

(End of clause)

852.229-70--852.229-71 [Reserved]

852.232-70 Payments Under Fixed-Price Construction Contracts (Without NAS-CPM).

As prescribed in 832.111-70, insert the following clause in contracts that do not contain a section entitled “Network Analysis System - Critical Path”

Payments Under Fixed-Price Construction Contracts (Without NAS-CPM) (NOV 2018)

The clause FAR 52.232-5, Payments Under Fixed-Price Construction Contracts, is implemented as follows:

(a) Retainage.

(1) The Contracting Officer may retain funds -

(i) Where performance under the contract has been determined to be deficient or the Contractor has performed in an unsatisfactory manner in the past; or

(ii) As the contract nears completion, to ensure that deficiencies will be corrected and that completion is timely.

(2) Examples of deficient performance justifying a retention of funds include, but are not restricted to, the following -

(i) Unsatisfactory progress as determined by the Contracting Officer;

(ii) Failure to meet schedule in Schedule of Work Progress;

(iii) Failure to present submittals in a timely manner; or

(iv) Failure to comply in good faith with approved subcontracting plans, certifications, or contract requirements.

(3) Any level of retention shall not exceed 10 percent either where there is determined to be unsatisfactory performance, or when the retainage is to ensure satisfactory completion. Retained amounts shall be paid promptly upon completion of all contract requirements, but nothing contained in this paragraph (a)(3) shall be construed as limiting the Contracting Officer's right to withhold funds under other provisions of the contract or in accordance with the general law and regulations regarding the administration of Government contracts.

(b) The Contractor shall submit a schedule of cost to the Contracting Officer for approval within 30 calendar days after date of receipt of notice to proceed. Such schedule will be signed and submitted in triplicate. The approved cost schedule will be one of the bases for determining progress payments to the Contractor for work completed. This schedule shall show cost by the work activity/event for each building or unit of the contract, as instructed by the resident engineer.

(1) The work activities/events shall be subdivided into as many sub-activities/events as are necessary to cover all component parts of the contract work.

(2) Costs as shown on this schedule must be true costs and the resident engineer may require the Contractor to submit the original estimate sheets or other information to substantiate the detailed makeup of the schedule.

(3) The sums of the sub-activities/events, as applied to each work activity/event, shall equal the total cost of such work activity/event. The total cost of all work activities/events shall equal the contract price.

(4) Insurance and similar items shall be prorated and included in the cost of each branch of the work.

(5) The cost schedule shall include separate cost information for the systems listed in the table in this paragraph (b)(5). The percentages listed in the following table are proportions of the cost listed in the Contractor's cost schedule and identify, for payment purposes, the value of the work to adjust, correct and test systems after the material has been installed. Payment of the listed percentages will be made only after the Contractor has demonstrated that each of the systems is substantially complete and operates as required by the contract.

Value of Adjusting, Correcting, and Testing System
System	Percent
Pneumatic tube system	10
Incinerators (medical waste and trash)	5
Sewage treatment plant equipment	5
Water treatment plant equipment	5
Washers (dish, cage, glass, etc.)	5
Sterilizing equipment	5
Water distilling equipment	5
Prefab temperature rooms (cold, constant temperature)	5
Entire air-conditioning system (Specified under 600 Sections)	5
Entire boiler plant system (Specified under 700 Sections)	5
General supply conveyors	10
Food service conveyors	10
Pneumatic soiled linen and trash system	10
Elevators and dumbwaiters	10
Materials transport system	10
Engine-generator system	5
Primary switchgear	5
Secondary switchgear	5
Fire alarm system	5
Nurse call system	5
Intercom system	5
Radio system	5
TV (entertainment) system	5

(c) In addition to this cost schedule, the Contractor shall submit such unit costs as may be specifically requested. The unit costs shall be those used by the Contractor in preparing its bid and will not be binding as pertaining to any contract changes.

(d) The Contracting Officer will consider for monthly progress payments material and/or equipment procured by the Contractor and stored on the construction site, as space is available, or at a local approved location off the site, under such terms and conditions as the Contracting Officer approves, including but not limited to the following -

(1) The materials or equipment are in accordance with the contract requirements and/or approved samples and shop drawings;

(2) The materials and/or equipment are approved by the resident engineer;

(3) The materials and/or equipment are stored separately and are readily available for inspection and inventory by the resident engineer;

(4) The materials and/or equipment are protected against weather, theft and other hazards and are not subjected to deterioration; and

(5) The Contractor obtains the concurrence of its surety for off-site storage.

(e) The Government reserves the right to withhold payment until samples, shop drawings, engineer's certificates, additional bonds, payrolls, weekly statements of compliance, proof of title, nondiscrimination compliance reports, or any other requirements of this contract, have been submitted to the satisfaction of the Contracting Officer.

(f) The Contracting Officer will notify the Contractor in writing within 10 calendar-days of exercising retainage against any payment in accordance with FAR clause 52.232-5(e). The notice shall disclose the amount of the retainage in value and percent retained from the payment, and provide explanation for the retainage.

(End of clause)

Alternate I (Nov 2018). If the specifications include guarantee period services, the Contracting Officer shall include the following paragraphs as additions to paragraph (b) of the basic clause:

(6)(i) The Contractor shall at the time of contract award furnish the total cost of the guarantee period services in accordance with specification section(s) covering guarantee period services. The Contractor shall submit, within 15 calendar days of receipt of the notice to proceed, a guarantee period performance program that shall include an itemized accounting of the number of work-hours required to perform the guarantee period service on each piece of equipment. The Contractor shall also submit the established salary costs, including employee fringe benefits, and what the Contractor reasonably expects to pay over the guarantee period, all of which will be subject to the Contracting Officer's approval.

(ii) The cost of the guarantee period service shall be prorated on an annual basis and paid in equal monthly payments by VA during the period of guarantee. In the event the installer does not perform satisfactorily during this period, all payments may be withheld and the Contracting Officer shall inform the Contractor of the unsatisfactory performance, allowing the Contractor 10 days to correct deficiencies and comply with the contract. The guarantee period service is subject to those provisions as set forth in the Payments and Default clauses.

852.232-71 Payments Under Fixed-Price Construction Contracts (Including NAS-CPM).

As prescribed in 832.111-70, insert the following clause in contracts that contain a section entitled “Network Analysis System - Critical Path Method (NAS-CPM).”

Payments Under Fixed-Price Construction Contracts (Including NAS-CPM) (NOV 2018)

The clause FAR 52.232-5, Payments Under Fixed-Price Construction Contracts, is implemented as follows:

(a) Retainage.

(1) The Contracting Officer may retain funds -

(i) Where performance under the contract has been determined to be deficient or the Contractor has performed in an unsatisfactory manner in the past; or

(ii) As the contract nears completion, to ensure that deficiencies will be corrected and that completion is timely.

(2) Examples of deficient performance justifying a retention of funds include, but are not restricted to, the following -

(i) Unsatisfactory progress as determined by the Contracting Officer;

(ii) Failure to meet schedule in Schedule of Work Progress;

(iii) Failure to present submittals in a timely manner; or

(iv) Failure to comply in good faith with approved subcontracting plans, certifications, or contract requirements.

(3) Any level of retention shall not exceed 10 percent either where there is determined to be unsatisfactory performance, or when the retainage is to ensure satisfactory completion. Retained amounts shall be paid promptly upon completion of all contract requirements, but nothing contained in this paragraph (a)(3) shall be construed as limiting the Contracting Officer's right to withhold funds under other provisions of the contract or in accordance with the general law and regulations regarding the administration of Government contracts.

(b) The Contractor shall submit a schedule of costs in accordance with the requirements of section “Network Analysis System - Critical Path Method (NAS-CPM)” to the Contracting Officer for approval within 90 calendar days after date of receipt of notice to proceed. The approved cost schedule will be one of the bases for determining progress payments to the Contractor for work completed.

(1) Costs as shown on this schedule must be true costs and the resident engineer may require the Contractor to submit its original estimate sheets or other information to substantiate the detailed makeup of the cost schedule.

(2) The total costs of all work activities/events shall equal the contract price.

(3) Insurance and similar items shall be prorated and included in each work activity/event cost of the critical path method (CPM).

(4) The CPM shall include a separate cost loaded activity for adjusting and testing of the systems listed in the table in paragraph (b)(5) of this clause. The percentages listed in paragraph (b)(5) will be used to determine the cost of adjust and test work activities/events and identify, for payment purposes, the value of the work to adjust, correct and test systems after the material has been installed.

(5) Payment for adjust and test activities will be made only after the Contractor has demonstrated that each of the systems is substantially complete and operates as required by the contract.

Value of Adjusting, Correcting, and Testing System
System	Percent
Pneumatic tube system	10
Incinerators (medical waste and trash)	5
Sewage treatment plant equipment	5
Water treatment plant equipment	5
Washers (dish, cage, glass, etc.)	5
Sterilizing equipment	5
Water distilling equipment	5
Prefab temperature rooms (cold, constant temperature)	5
Entire air-conditioning system (Specified under 600 Sections)	5
Entire boiler plant system (Specified under 700 Sections)	5
General supply conveyors	10
Food service conveyors	10
Pneumatic soiled linen and trash system	10
Elevators and dumbwaiters	10
Materials transport system	10
Engine-generator system	5
Primary switchgear	5
Secondary switchgear	5
Fire alarm system	5
Nurse call system	5
Intercom system	5
Radio system	5
TV (entertainment) system	5